Bahrain: Liquidated Damages After Termination: Court Of Appeal Calls Time On The Uncertainty?

Last Updated: 27 June 2019
Article by Christopher Busaileh

Introduction

Commercial contracts where one party is obliged to supply goods or services by a specified date often contain liquidated damages clauses. These clauses set a pre-determined level of damages that a party is entitled to recover should delivery or completion not take place by the specified date. Construction contracts commonly use liquidated damages clauses to set the damages to be paid by the contractor to the employer in the event of delay beyond the stated completion date.

The commercial rationale is clear; liquidated damages promote certainty and avoid the need for the innocent party to establish its actual losses as a result of the delay (which can often be very costly and protracted).

However, there has been uncertainty as to whether liquidated damages could be levied in circumstances where the project is in delay and the employer terminates the contractor's employment before completion takes place. There are a number of conflicting decisions on this point, with the English Courts adopting three broad approaches:

  1. Liquidated damages fall away completely and the employer may only claim general damages. The clause will only apply to those parts of the works (if any) which have been completed prior to termination.
  2. The employer can levy liquidated damages up-to the date of termination. Thereafter, he must claim general damages for loss arising from delay.
  3. The employer can levy liquidated damages up-to the date of completion by a replacement contractor.

In the recent case of Triple Point Technology ('TPT') v PTT Public Company ('PTT'), concerning a software supply agreement, the Court of Appeal has provided guidance on this topic, which may impact how liquidated damages and the consequences of termination are drafted in contracts.

Facts

TPT supplied software to PTT and the contract provided for various milestones to be achieved. If the supply was delayed beyond the milestones, TPT was liable to pay liquidated damages from the due date for delivery "up to the date PTT accepts such work".

Stages 1 and 2 of the project were completed (and accepted by PTT), albeit they were 149 days late. However, PTT terminated the contract before the subsequent stages had been completed. At the point of termination, the project was in significant delay. In the litigation that followed, one of the issues before the court was whether PTT was entitled to rely on the liquidated damages clause and, if so, whether the liquidated damages accrued up to the date of termination or beyond.

The initial finding of the Technology and Construction Court was that PTT was entitled to liquidated damages. In respect of stages 1 & 2 (i.e. the completed stages) this was up-to the date of completion and, in respect of the incomplete stages, up until the date of termination.

Appeal

The Court of Appeal agreed with the TCC's approach to stages 1 & 2 but disagreed in respect of its approach to the incomplete stages. It found that the specific reference in the contract that liquidated damages were to be applied "up to the date PTT accepts such work", indicated that the clause could only apply in a situation where the original contractor complete the work. It did not and could not apply to sections of work which remained incomplete at termination. Therefore, in respect of those incomplete stages, PTT would need to prove its losses as general damages.

As to more general guidance, the court confirmed that there is no hard and fast rule. The impact of termination on any liquidated damages clause depends on the particular wording of the clause. That said, the judgment hints towards a preference to the first of the above approaches, i.e. the clause falls away entirely, rather than either of the other approaches, despite the more recent court decisions favouring these. 

Comment

The Court's guidance provides welcome clarity as to the approach the courts will take. However, an employer's ability to claim liquidated damages following a termination, depends on the specific contract provisions. The wording of the various standard forms of construction contracts take different (intentional or not) approaches. In certain contracts, if not specifically amended, the wording could result in an employer not being able to recover liquidated damages in circumstances where termination occurs prior to completion.

By way of example, NEC4 states that liquidated damages are payable until the earlier of 'Completion' and taking over of the works. Completion, as defined, can only ever be achieved by the original contractor and so it seems likely that the liquidated damages clause would fall away if termination occurs prior to "Completion".

In contrast, the termination provisions in FIDIC forms of contract specifically refer to the employer being entitled to payment of liquidated damages up-to the date of termination and would seemingly satisfy the Court of Appeal's analysis in TPT v PTT that general damages only apply to post termination losses.

Whichever form of contract parties intend to use, prior to entering into contract they should carefully consider whether they are content to rely on general damages in circumstances where termination occurs prior to completion or whether liquidated damages are preferable. Depending on the answer, it may well be the case that the standard provisions will require amendments.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
 
Related Articles
 
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions