United States: Contractors Should Prepare For Potential Shutdown

Last Updated: January 19 2018
Article by Daniel E. Chudd, Kathy Weinberg and Victoria Dalcourt

As Congress and the Administration appear to be careening toward a potential government shutdown – whether on Friday January 19 or once another short-term continuing resolution expires – it is a good time for government contractors to review their contracts and the potential effect a shutdown might have.

The Antideficiency Act mandates a partial government shutdown when Congress fails to appropriate annual funds. In such situations, agencies with a funding gap will be required to shut down all but a narrowly defined set of essential services and operations. The Act also prohibits the government in such situations from creating new obligations, such as awarding contracts, issuing task orders, exercising options, and making related payments in the absence of a sufficient appropriation legally available for that purpose. Additionally, the Act precludes many government employees from working during government shutdowns. However, there are exceptions for "essential" work and personnel.

In the event of a shutdown, the likely impact on contractors will largely depend upon the length of the shutdown and the nature of a company's contracts with the government. The least-impacted contracts are likely to be those that are fully funded, require minimal government supervision, and are unaffected by facility closures. In contrast, the most-impacted contracts are likely to be incrementally funded contracts for nonessential services, particularly where potentially furloughed government personnel or access to closed government facilities are necessary for the contractor to perform. A shutdown is also likely to affect the time of payment for work being performed on a contract as well as lead to potential contract schedule disruption and delays in procurement of new contracts.

Right to Payment Under Existing Contracts

One of the first questions contractors may have is whether they will have a right to be paid for continued work under existing contracts. This question largely depends on the type of contract and whether it has been fully funded. All cost-reimbursable contracts should contain either a limitation of funds or limitation of costs clause. These clauses are based on the basic assumption that the contractor should continue work that is adequately funded and should discontinue work that is not adequately funded. If a contractor continues to work even though funding has not been added to the contract to cover such continued work, the contractor does so at its own risk, regardless of the reason for the lack of funding. Even after a budget crisis is over, the Government is not required – morally, legally, or contractually – to add funds to the contract to retroactively cover work done in the absence of funding.

On the other hand, the Government cannot require continued performance after funding limits have been reached. While it may not be cost-effective – for the Government – for the contractor to stop work during a funding lapse, it is the only safe course for contractors. These rules, covering funding lapses in individual contracts, apply with equal or greater force when the funding lapses are caused by government shutdowns.

In contrast to cost-reimbursable contracts, fixed-price contracts normally are fully funded at the time of award. That means that funding concerns should not interfere with payment. According to DoD's contingency plan for 2015, contractors "performing under a fully funded contract (or contract option) that was awarded prior to the expiration of appropriations may continue to provide contract services, whether in support of excepted activities or not." Memorandum from Deputy Secretary of Defense dated September 25, 2015, "Guidance for Continuation of Operations During a Lapse of Appropriations." However, no contract options can be exercised, and no orders can be issued, and funding increments cannot be added, unless the contract is to support an excepted activity, e.g., military operations; recruiting activities; command, control, communications, computer, intelligence, surveillance, and reconnaissance activities required to support national or military requirements necessary for national security; activities to carry out or enforce treaties; emergency repair and non-deferrable maintenance for utilities; control of hazardous materials; foreign humanitarian assistance; activities to protect military personnel or property; etc. Although this 2015 guidance may not be applicable to a 2017 shutdown, a link to it (as well as many other sets of guidance from 2015) is currently posted on OMB's website (https://www.whitehouse.gov/omb/information-for-agencies/Agency-Contingency-Plans).

Effect on Time of Payment

Even where a contractor may have a right to get paid for continuing work for a shutdown, that right is only for the contractor to get paid eventually. During and even immediately after the shutdown, the Government may not be able to make timely payments for work that is performed. Contractors should therefore expect and prepare for delays in payment caused by a shutdown. This is especially important given that payment delays do not ordinarily excuse performance. Some businesses whose continued survival is dependent upon prompt payment may be entitled to use payment delays as excuses, but most companies will have to continue performance of funded operations even though they encounter payment delays.

Schedule and Price Adjustments for Delays

Shutdown-related government actions, or failures to act, that cause delays to contractor operations should give rise to a right to an equitable adjustment in the contract schedule. While a shutdown is likely a sovereign act, as discussed below, that will provide a defense to a claim for money, not to a claim for additional time to perform or a challenge to a wrongful default termination.

Even if funds are available to continue performance, lack of government personnel could impact performance. For example, if government inspectors must approve first article testing before the contractor is authorized to start production, then the absence of government inspectors can effectively slow or stop performance. Similarly, if the contractor is unable to proceed without government direction, and such direction is not forthcoming, the contractor may have to delay performance until it receives such direction.

Contractors may be able to use advance planning to lessen the effects of a shutdown in such situations. If the contractor can continue to perform without government supervision, on a contract that is fully funded, the contractor cannot use the shutdown as an excuse for non-performance.

In contrast to the schedule adjustments, contractors may have a more difficult time claiming any price adjustments as a result of a shutdown because the shutdown is likely to be deemed a sovereign act. As one Board explained in a shutdown-related case in 2000, the "governmental action's impact upon specific public contracts is merely incidental to the accomplishment of a broader governmental objective." Raytheon STX, Corp. v. Department of Commerce, GSBCA No. 14296-COM, 00-1 BCA ¶ 30,632; see also A-1 Real Estate, Inc., 1997 HUD BCA LEXIS 7, ("the legislative branch's failure to appropriate funds for certain Federal operations, thereby creating a government shutdown, falls within the ambit of a 'sovereign act' having manifest 'public and general' application.").

On exception may be if funds are made available to continue government operations at some level, then funding decisions by the agency (to fund some contracts but fail to fund others) may not constitute sovereign acts. In some cases, contractors can recover where "the funding shortage and work shutdown at issue were not due to any sovereign act by Congress which had not delayed in appropriating funds when so requested by the agency, but rather to the agency's own decisions in administering the contract." Cyrus Contr., Inc., 1998 IBCA LEXIS 9.

In addition, if the Contracting Officer takes any contractual action to effectuate, rather than just to communicate, the shutdown, it may be possible to argue that there has been a contractual action or a waiver of sovereign immunity. The Government can use any of its typical tools to control actions during a shutdown. These include issuing change orders or terminations for convenience and can delay, suspend, or stop work on contracts. All of these contractual actions, however, will give rise to the contractor's right to obtain the remedies specified in the contract. Thus, contracting officers were warned not to take contractual actions to effectuate the shutdown unless absolutely necessary.

Finally, the contracts themselves may also contain provisions constituting an allocation of risk of non-performance, costs, or delays, and those risk-allocation provisions may not be deemed to except the risks of government shutdowns. A careful review of a contractors major contracts may reveal risk-shifting provisions that could help identify future claims for increased costs.

What Should Contractors Do?

There are three steps that every government contractor should take to prepare for a possible government shutdown.

1. Review Your Contracts

First, review whether any clauses, special provisions, or other requirements in your contracts will apply during a funding gap or continuing resolution. This includes any obligations to continue working during the period based on the work being designated in the contract as essential to national security.

Second, review contracts with an eye toward the amount and type of contract funding. Incrementally funded contracts should contain either the Limitation of Cost clause, FAR 52.232-20, or the Limitation of Funds Clause, FAR 52.232-22, while contracts contingent on future fiscal year funding should contain the Availability of Funds clause, FAR 52.232-18. Reviewing how contracts are funded can give contractors insight into what work is likely to continue, and what is likely to stop, which is valuable for planning purposes (see step two for developing a shutdown contingency plan).

Third, check whether your contracts allocate shutdown-related risk to a particular party. Contracts may allocate risk of a shutdown to the government. If such contractual provisions can be identified in a contract, it is possible for contractors to recover the "out-of-pocket expenses" arising from the interruption of contract performance caused by a government shutdown.

Fourth, check to see whether any of your contracts set to expire before or shortly after the end of the fiscal year contain an extension or option clause. In such cases, contractors should consider asking for an extension so that renewal does not come due when agency contracting staff are potentially furloughed.

2. Develop a Shutdown Contingency Plan

Start by reviewing agency shutdown contingency plan guidance.

In the unlikely event of a shutdown, agencies will publish contingency plan guidance for the continuation of essential operations in the absence of available appropriations that will contain relevant information for contractors. To plan ahead, contractors can find contingency plan guidance published by agencies from previous years.

Plans should address what contractors will do with employees working on contracts that are subject to stop-work orders. In 2013, some contractor employees were laid off, furloughed, or required to use leave or take paid or unpaid time off during the shutdown. The ability of contract workers to be paid during the shutdown depended upon whether work was allowable based on the terms of the contract that they worked on and the availability of other assignments. Contractors should consider whether workers can be reassigned to other work, made to take vacation, or furloughed. Additionally, contractors should implement a system for notifying employees in the event of a shutdown.

Plans should establish a system for documenting all expenses, actions, and communications. In the event of a shutdown, contractors should document all communications, particularly instructions or directions for performance and assurances of payment. As mentioned above, in the event of a government shutdown, it may be possible to recover any resulting "out-of-pocket expenses." Contractors should carefully record all expenses, including the costs of winding down and resuming contract activities.

Plans should address practicalities such as how to ensure access to government buildings if contracted work is deemed "essential." If work is to continue during a shutdown, contractors should establish a plan in collaboration with government employees on site regarding how contract workers will have access to government facilities should a shutdown take place.

3. Communicate with Your Contracting Officer

During the government shutdown in 2013, contract management officials who were furloughed could not communicate with contractors to respond to questions. In anticipation of similar lapses in communication, contractors should reach out to contract officers now. Contractors can take this opportunity to verify important information such as:

  • The funding status of your contracts (if it is not clear from the contract documents)
  • Which facilities will remain open in the event of a shutdown
  • Whether equipment and/or personnel needed for performance will be available during a shutdown
  • Whether a contract is subject to any exceptions
  • What the agency's plan is with respect to continuing performance in the event of a shutdown

While contracting officers may not have the desired information readily available, reaching out to them now to establish a rapport may be beneficial, as you are more likely to be promptly informed of new information as it becomes available.

Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Morrison & Foerster LLP. All rights reserved

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Daniel E. Chudd
Victoria Dalcourt
Similar Articles
Relevancy Powered by MondaqAI
Fox Rothschild LLP
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Fox Rothschild LLP
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions