United States: Builders Risk Insurance: Resurrecting The Project After The Storm

Gregory Meeder and James Chivilo are Partners at our Chicago office



Best Practices for Securing Coverage for Project and Claim Costs After Major Loss Events

HIGHLIGHTS:

  • Catastrophic storms such as Hurricane Harvey and Hurricane Irma invariably cause property damage, schedule delays and other "soft costs" when they hit during a project's construction.
  • Owners and contractors engaged in ongoing construction projects may experience both covered project losses and noninsured contract damages as a result of these rare and unpredictable weather events. Builder's risk insurance provides coverage for damages to insured property resulting from wind, flood, rain, windstorms, hurricanes and tropical storms.
  • An experienced understanding of builder's risk insurance coverage, its common policy terms and the process and planning for proceeding with project and contract claims after catastrophic events will be critical to maximizing coverage and recovery for project and contract losses.

Catastrophic storms such as Hurricane Harvey and Hurricane Irma invariably cause property damage, schedule delays and other "soft costs" when they hit during a project's construction. Owners and contractors engaged in ongoing construction projects may experience both covered project losses and noninsured contract damages as a result of these rare and unpredictable weather events. Builder's risk insurance provides coverage for damages to insured property resulting from wind, flood, rain, windstorms, hurricanes and tropical storms. Exclusions to coverage often lead to contract claims under a number of contract clauses which can exceed insured claims.

Most insureds are unaware that unlike commercial general liability policies and other formalized polices of insurance, builder's risk polices are usually not written on standardized insurance industry coverage forms. Although the Insurance Services Office drafted a standardized builder's risk policy form, it is a general practice for insurance companies to issue builder's risk insurance on their own manuscripted forms. Given the variations, there are always nuances to a builder's risk claim. As a result, insurance industry and claim handling experience will benefit a client's claim process. An experienced understanding of builder's risk insurance coverage, its common policy terms and the process and planning for proceeding with project and contract claims after catastrophic events will be critical to maximizing coverage and recovery for project and contract losses.

General Policy Understanding

Most builder's risk insurance policies do not require a formal claim or suit to trigger coverage under policy terms. Builder's risk insurance provides coverage for defined property, resulting from specified perils for specifically named insureds. These policies provide coverage for ongoing construction projects along with specified materials, designs, plans, infrastructure and equipment that is designated to become a permanent part of project. There can be several exclusions for project-based claims that could include project defects, construction equipment, existing buildings, various definitions of "land" where the project is located, tools, temporary buildings, infrastructure and technology used in the process of construction.

Furthermore, most policies describe exclusions for delay, scheduling and other "soft costs" or contract-based claims. The scope of these exclusions may vary and terms exist that may actually allow such claims through policy riders and endorsements. An insured may also fail to realize that "soft costs" may be covered because of complicated policy terms and provisions. For example, some polices are structured to exclude consequential damages but separately provide coverage for expedited construction costs, expenses, consultant costs, professional fees, costs to prepare a claim and work to reinstate the project. Recognizing and proceeding with "soft cost" claims is important to ensure timely completion of the project, manage future project costs and provide coverage for contract change orders or overruns as a result of covered damages. These provisions may also allow for recovery of attorney's fees for the insured.

General practitioners and project team members should understand the context and format to submit claims. Policy conditions prescribe detailed claim forms, procedures and deadlines for claim submission and disputes after adjustments for claim losses. An insured must honor these requirements because failure to cooperate could result in the denial of a part of or the entirety of the claim.

Claim Handling

It is critically important for an insured to plan for an organized claim handling and submission process. There are five best practices when proceeding with a builder's risk claim with significant project losses.

  • Create the claim team. This will include legal counsel, those with the most knowledge about the project (pre-occurrence event), those with knowledge about the project as a result of the cause of loss, engineers, contractors, accountants, the insured's insurance broker and corporate risk managers.
  • Designate one point of organized contact with the insurance adjuster to provide details for the claim. Insured's must take care to determine what they write or say to the insurer and when they do so. In nearly all cases the point of contact includes legal counsel for the insured. The information provided to the adjuster will be used for and against the insured when adjusting claim losses based upon the facts and information provided to the insurer. Counsel for an insured will help establish the protections of attorney client, work product and other applicable privileges to protect sensitive information.
  • Secure and certify the entire builder's risk insurance policy. A builder's risk policy generally includes declarations, an insuring agreement, exclusions, conditions, additional expansions of coverage, endorsements and policy jackets or covers. The terms of the policy will provide the road map to recovery and detail the coverage for the claim. Certifying the entire scope of the applicable policy will be important to maximize and plan for the claim submission.
  • Begin to document and process losses carefully and accurately. Project accountants can create separate project codes or accounting codes. This process can also allow for separate tracking of "soft costs," which includes project administration costs, overhead, financing costs, design fees, taxes, lost profits, travel and/or transportation.
  • Notify all carriers. Large value builder's risk coverage is usually underwritten through a syndicated insurance policy. This means that although there will be only one policy, there may be several different insurance companies with an agreed percentage of risk. It is important to identify all syndicated carriers and make sure to coordinate to place them on notice of the claim as early as possible.

Conclusion

Although damages caused by major events can be destructive, proper preparation of a builder's risk claim will maximize recovery of project losses. Industry professionals with claim experience will add value to the claims process. Many insurance brokers are not licensed in the United Kingdom where many of these catastrophic policies are underwritten by insurance syndicates. Without a clear understanding of the potential noncovered contract claims and the covered claims under the builder's risk policy, both contractors and owners may be underrepresented by qualified advisors. It is important to take a comprehensive approach to a coordinated claim that will reinstate the project, recover the project schedule and minimize damages and costs to all parties involved.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions