United States: Constructive Change: A Claim By Any Other Name

What should a contractor do when it and the owner's representative dispute whether certain work requested by the owner is required by the drawings and specifications and the contract states that (1) the contractor waives its right to a change order by proceeding to perform a change without first obtaining a change order or directive signed by the owner's representative, and (2) the contractor is obligated to continue performance of the work pending resolution of a disputed claim?

If the contractor is right that the work is in addition to what is required by the drawing and specifications, the contractor may perform the work without a change order or directive signed by the owner's representative and still is entitled to extra compensation and time under the constructive change doctrine.

In contrast to an express change, which is a change acknowledged (normally in writing) by the owner, a constructive change occurs when an owner makes a change to a contractor's work without recognizing or admitting that it is doing so. The doctrine of 'constructive change' is a legal fiction created "by the federal judiciary and federal boards of contract appeal to (1) remediate contractor claims for extra work, and (2) permit contractors to perform disputed work without having to risk abandonment of their contracts to preserve their claims. The theory underlying the constructive change concept is that where the government 'should have' issued a change order authorizing the extra work in the first place, the court or board may direct the government to do what 'should have been done' by directing the government to issue a formal change order. The doctrine in its modern guise is the embodiment of the ancient equitable principle that 'what should have been done will be done.'"1

Because the doctrine of constructive change has its roots in federal contract disputes, the doctrine is most commonly recognized in the context of a contract with a federal government entity. However, the doctrine is also alive and well in most state2, local and private construction disputes.3 For example, the Georgia Department of Administrative Services State Purchasing Division expressly recognizes the doctrine in its "Georgia Procurement Manual."4

The Board of Contract Appeals described the two key elements to asserting a successful constructive change as follows:

As we see it, the constructive change doctrine is made up of two elements – the "change element" and the "order" element. To find the change element we must examine the actual performance to see whether it went beyond the minimum standards demanded by the terms of the contract. But, this is not the end of the matter.

The "order" element also is a necessary ingredient in the constructive change concept. To be compensable under the changes clause, the change must be one that the Government orders the contractor to make. The Government's representative, by his words or his deeds, must require the contractor to perform work which is not a necessary part of his contract. This is something which differs from advice, comments, suggestions, or opinions which Government engineering or technical personnel frequently offer to a contractor's employees.5

For a contract to be constructively changed, the plaintiff must prove that the government expressly or implicitly ordered the contractor to perform work that was outside the contract requirements. The Federal Court of Claims in Miller Elevator Co. v. United States, stated

Thus, if the Government either expressly or implicitly ordered work outside the scope of the contract, or if the Government otherwise caused the contractor to incur additional work, a constructive change arises for that work performed outside of the scope of the contract. While the constructive change doctrine provides a means for a contractor recovery, the rationale for constructive changes involves the objective of persuading a contractor to continue to work pending resolution of any dispute involving the work at issue.6

In Miller Elevator Co. v. United States, a dispute arose out of an elevator maintenance contract between a contractor and a federal agency for the contractor to perform maintenance services for a federal office building. Sixteen months after the execution of the maintenance contract, the federal agency authorized substantial renovations to the building. The elevator contractor argued that the amount and extent of work required to maintain the building elevators during the renovations far exceeded the scope of work contemplated in the maintenance contract.

With respect to the "change" component, the Court found that the scope of work required of the contractor extended well beyond that contemplated by the contract at issue, which did not contemplate the renovations undertaken at the building. As for the "order/fault" component, the Court found that the Government either authorized the work before acceptance or allowed the performance of the work followed by acceptance. Accordingly, the Court of Federal Claims held that the contractor was entitled to an equitable adjustment under the contract to maintain elevators because the agency authorized substantial renovations to the building which required additional maintenance to comply with the contract terms.7

Constructive changes have been applied by the courts in five distinct situations: "(I) disputes over contract interpretation during performance; (II) government (or owner) interference or failure to cooperate; (III) defective specifications; (IV) misrepresentation and nondisclosure of superior knowledge; and (V) acceleration."8 In Miller Elevator Co. v. United States, the contractor sought to prove a Type I constructive change (i.e., disputes over contact interpretation during performance) by asserting the occurrence of constructive changes to its maintenance contract by the direction of government representatives to perform work outside of the scope of the contract at issue.

Due to space limitations, this article does not address all five situations where the courts have recognized constructive changes. However, the two elements that must be present to assert a successful constructive change – (1) the change element and (2) the order element – must be understood by contractors hoping to recover for actions or inactions by the Owner, or those for whom the Owner is responsible, that necessitate a change that the Owner does not acknowledge as a change.

A court is likely to analyze a constructive change claim using the two essential elements discussed in this article. With that understanding in mind, a contractor hoping to preserve a constructive change claim should follow some common-sense rules, including:

  • If you think you've encountered a constructive change situation, you should document what acts or inactions by the owner necessitated the change before performing the change work;
  • You should remember to carefully document all costs and added time associated with the constructive change, and you should preserve all correspondence with the owner notifying it of the extra costs and time associated with the constructive changes; and
  • You must also carefully review and follow the notice provisions of your contract regarding changes and/or claims9 because you could waive your right to compensation for constructive changes if you cannot prove that you complied with the contractual notice requirements.

The above list is not exhaustive and the authors recommend that you consult your attorney if you believe you are entitled to a constructive change order and have questions about preserving your rights with respect to your claim.

Footnotes

1. 1 Bruner & O'Connor Construction Law § 4:25

2. See, e.g., Sentinel Indus. Contracting Corp. v. Kimmins, 743 So. 2d 954 (Miss. 1999) (ruling that the concept of "constructive change orders" was not recognized under Mississippi law, but allowing recovery for extra-contractual work under principles of equitable estoppel or implied-in-fact contracts).

3. Because the phrase "constructive change" originates from jurisdictional issues in the federal contracting context, the phrase is most commonly used in federal cases. Cases under state or local laws are typically referred to as "claims" or "breaches of contract," but they proceed on the same theory of recovery as the constructive change doctrine and sometimes the phrase constructive changes will be used by state courts. See, e.g., Global Constr. v. Missouri Hwy., 963 S.W.2d 340 (Mo. App. W.D. 1997)

4. Georgia Procurement Manual, Department of Administrative Services State Purchasing Division (2010), http://doas.ga.gov/assets/State%20Purchasing/GPM%20Documents/GPM-A1-2010.pdf (last visited November 27, 2016) (stating that constructive changes may occur when state entity personnel: (1) provide suggestions to a contractor, (2) provide definitions to general contract terms, (3) accelerate the delivery schedule, (4) direct the work to be performed differently, (5) change the sequencing of the work, (6) delay accepting or rejecting deliverables, (7) delay reviewing invoices and approving payment, (8) interfere with or hinder performance, or (9) add to the scope of work).

5. Industrial Research Associates, Inc., DCAB No. WB-5, 68-1 BCA ¶ 7069, pp 32, 685-86.

6. 30 Fed. Cl. 662, 678.

7. 30 Fed. Cl. 662, 678-708.

8. Miller Elevator Co. v. United States, 30 Fed. Cl. 662, 678 (1994).

9. Many contracts, including standard form contracts, provide a basis for recovery of constructive changes but they do not normally use the phrase "constructive change." For example, the American Institute of Architects ("AIA") refers to the constructive change as a "claim." Paragraph 15.1.1 of the AIA A201-2007 General Conditions provides that "a claim is a demand or assertion by one of the parties seeking, as a matter of right, payment of money, or other relief with respect to the terms of the contract." You may consult an attorney to determine if your contract provides specific notifications requirements for asserting a constructive change.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions