United States: Contractor Barred From Using The "Total Cost" Or "Modified Total Cost" Approach To Establish Delay Claim

Last Updated: July 21 2015
Article by F. Keith Covington

In a recent ruling, Hill York Service Corporation v. Critchfield Mechanical, Inc., the U.S. District Court for the Southern District of Florida held that a contractor may not establish damages for delay under either the "total cost" approach or the "modified total cost" approach when there is evidence attributing some of the delay to the contractor, and no apportionment of the costs has been made for the contractor's delays.

Critchfield Mechanical, Inc. ("CMI") was a mechanical contractor on the Air Force Technical Applications Center project ("the Project") at Patrick Air Force Base in Florida. The Project involved the design and construction of four separate facilities at the Base, including a headquarters building, a process support and laboratory building, a central utility plant, and an underground utility vault. CMI was responsible for creating and delivering to the Project certain major mechanical equipment, including air handling units that were to be set on the roofs and in the interiors of the headquarters building and the process support and laboratory building.

In May 2012, Hill York was awarded the piping subcontract by CMI. Hill York installed the pipe, valves, fittings, and appurtenances in the CMI equipment. Hill York claimed that it was forced to incur substantial extra labor and materials costs as a result of a number of delays caused by CMI. It alleged that CMI had delayed by several months the delivery of the air handling units for the headquarters building and the process support and laboratory building and that several of those late-delivered units were misfabricated, incomplete, and contained radical design changes. Hill York also claimed that its piping work on both the central utility plant and the underground vault was delayed for various reasons attributable to CMI, including late equipment deliveries, design changes, a premature storage of materials at the worksite, and a floor failure in the central utility plant.

Hill York sued CMI, claiming that CMI breached the parties' contract, "in part by knowingly 'failing to compensate Hill York for the impacts, inefficiencies of labor and extended performance due to changes in design, late equipment deliveries and limited access to work areas that Hill York encountered on the Project.'" Hill York sought to recover damages including labor costs and material/subcontract costs. CMI denied liability, asserting, among other things, that Hill York itself had caused significant delays on the Project.

CMI filed a motion for summary judgment, seeking to prevent Hill York from using either the total cost approach or the modified total cost approach to establish its delay damages at trial.

In analyzing CMI's summary judgment motion, the Court noted that "[t]he best proof of [a] delay claim is actual cost information taken from the [plaintiff] company's accounting books and records and accumulated in such a way that the damage calculation presents a direct cost for each item of delay." The Court, however, recognized that, in certain limited situations, a contractor may prove delay damages through other methods that are less precise than establishing the specific increased costs. Two of these recognized methods are the total cost approach and the modified total cost approach. Under the total cost approach, the difference between actual cost of the entire project and the original bid cost, after various adjustments and modifications, is the amount of damage incurred by the contractor. The modified total cost approach is a variant of the total cost approach that allows for an adjustment of the damage amount to compensate for bid errors, costs resulting from the contractor's own actions, and costs resulting from the actions of third parties.

The District Court noted that both the total cost approach and the modified total cost approach were available to prove delay damages only if the contractor could establish, as an initial matter, a number of specific elements. Among other things, in order to use the total cost approach, a contractor first has to show that it "is not responsible for any of the additional expense." Similarly, under the modified total cost approach, the contractor initially has to establish that it has "reasonably accounted for" that portion of the total costs for which it is responsible.

The District Court granted summary judgment for CMI, holding that Hill York was precluded from using either the total cost or the modified total cost approach to present its claim for delay damages to the jury. In ruling for CMI, the Court noted that CMI had presented unrebutted evidence of several problems attributable to Hill York, including late and incomplete shop drawing submittals, failing to have the materials necessary to do the piping work, hiring unnecessary workers, and performing an exorbitant number of punch list items after its work was substantially finished. Because Hill York could not show that it was not responsible for any of the extra costs sought and could not reasonably account for the extra costs it had caused, the Court held that Hill York could not avail itself of either the total cost or the modified total cost approach to prove its claim for delay damages.

The ruling means that, if and when the case goes to trial, Hill York will be required to prove its delay claim by presenting a specific accounting of the direct cost for each claimed item of delay. This case reiterates the principle that a contractor can recover only those damages for delay that it did not cause. To sustain a total cost claim, the contractor usually must show that its bid was reasonable, that there is no feasible or practicable way to allocate delays to specific items (because of the pervasive and interwoven nature of the delays), and that critical delays are attributable to the other party. Even though often criticized, the total cost method is often accepted when the contractor makes this showing. If a contractor cannot show these elements, it will have difficulty recovering for such delay under a total cost or modified total cost approach.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration
Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:
  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.
  • Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.
    If you do not want us to provide your name and email address you may opt out by clicking here
    If you do not wish to receive any future announcements of products and services offered by Mondaq you may opt out by clicking here

    Terms & Conditions and Privacy Statement

    Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

    Use of www.mondaq.com

    You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

    Disclaimer

    Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

    The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

    Registration

    Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

    • To allow you to personalize the Mondaq websites you are visiting.
    • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
    • To produce demographic feedback for our information providers who provide information free for your use.

    Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

    Information Collection and Use

    We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

    We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

    Mondaq News Alerts

    In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

    Cookies

    A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

    Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

    Log Files

    We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

    Links

    This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

    Surveys & Contests

    From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

    Mail-A-Friend

    If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

    Emails

    From time to time Mondaq may send you emails promoting Mondaq services including new services. You may opt out of receiving such emails by clicking below.

    *** If you do not wish to receive any future announcements of services offered by Mondaq you may opt out by clicking here .

    Security

    This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

    Correcting/Updating Personal Information

    If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

    Notification of Changes

    If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

    How to contact Mondaq

    You can contact us with comments or queries at enquiries@mondaq.com.

    If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.

    By clicking Register you state you have read and agree to our Terms and Conditions