United States: Will A Duty To Inspect The Site Adversely Affect A Differing Site Conditions Claim?

Last month, we discussed why utility contractors should insist on the inclusion of a differing site (changed) conditions ("DSC") clause in their contracts.  A DSC clause allocates to the owner the risk that actual physical conditions at the site are materially different from the expected physical conditions at the site, along with establishing a procedure for adjusting the contract price and time for DSCs.  Absent a properly drafted DSC clause, the doctrine of sanctity of contract normally places the risk on the contractor if the work is more difficult, costly, or time consuming than expected due to a DSC.

DSCs fall into two categories: Type I, which are physical conditions encountered during the performance of the work that differ materially from those indicated in the contract documents, and Type II, which are unknown physical conditions encountered during the performance of the work  that differ materially from the conditions normally encountered when performing such work.1

An owner is normally not liable to a contractor for a Type I DSC claim unless "the conditions actually encountered were reasonably unforeseeable based on all the information available to the contractor at the time of bidding." An owner is normally not liable to a contractor for a Type II DSC claim unless "the contractor could not reasonably have anticipated the actual condition at the site from inspection or general experience."  These standards generally obligate a contractor to conduct a reasonable inspection of the site and other available information at the time of bidding, even if the contract does not expressly require such an inspection.

In addition to the general obligation to conduct a reasonable inspection, most construction contracts expressly require that the contractor represent that it conducted an inspection of the site and other available information before contracting.  For instance, a typical site inspection clause represents that "...the Contractor has visited the site, become generally familiar with the local conditions under which the Work is to be performed and correlated personal observations with requirements of the Contract Documents."2

Reasonableness of a site inspection is based upon the scope, level, and amount of inspection that an ordinary, prudent contractor doing the same type of work would conduct under the same or similar circumstances.  A contractor is not held to the standard of an expert in any particular discipline, such as a geologist or engineer. Factors such as the time available to bidders, access, and other relevant facts and circumstances will affect whether a particular inspection is deemed reasonable.3

In addition to visiting the site, a contractor is responsible for considering all relevant information reasonably available to the contractor.  For example, the Court in Cook v. Oklahoma Board of Public Affairs4 held that a contractor's inspection was not reasonable because it failed to attend pre-bid conferences where site conditions were discussed, and it only made a hasty drive-through of the site.

A reasonable inspection also requires that the contractor understand and correlate the requirements of the contract documents with its observations of the site and other information.  The subcontractor in Hoffman Constr. Co.5 learned this lesson the hard way when it was denied recovery on a Type I DSC claim to recover the cost to remove 12,000 feet of hidden ductwork not shown in the plans for a renovation project. The specifications required the removal of all ductwork. The subcontractor visited the site, but it did not review the original plans for the building, which were available upon request. The court held that a reasonable, prudent contractor would have discovered the ductwork upon reviewing the original plans, and observing the ceiling grilles and registers connected to the ductwork during a site visit, which were in plain sight.

Interestingly, a contractor's failure to conduct an inspection will not, in all cases, preclude a contractor from recovering on a DSC claim. To recover on a DSC claim, the contractor must show, "...that the conditions actually encountered were reasonably unforeseeable based on all the information available to the contractor at the time of bidding," which includes information the contractor would have gained by visiting the site.6 Thus, a contractor can recover on a DSC claim, even if it failed to conduct an inspection, by showing that an ordinary, prudent contractor would not have discovered the DSC upon a reasonable inspection.7

Contractors should be aware that some owners include both a DSC clause and a disclaimer (avoidance clause) in their contracts in an attempt to narrow or even eliminate their risk for DSCs.  These avoidance clauses range from requiring an overly broad inspection to exculpating the owner from any liability for DSCs.  A typical avoidance clause would provide as follows:

Any representation in the Contract Documents purporting to indicate the physical conditions at the Site, including sub-surface and latent conditions, is for Contractor's information only.  In no event does Owner warrant the accuracy of such indications or that the actual physical conditions encountered will not vary from those indicated. All risk of differing subsurface conditions shall be borne solely by Contractor.

This type of clause could be interpreted to either narrow or conflict with a DSC clause.  To be enforceable, avoidance clauses must be clear and unambiguous. An avoidance clause that conflicts with a DSC to such an extent that it completely precludes recovery under a DSC clause is normally found unenforceable.

The Court in Metcalf Constr. Co., Inc. v. United States8 explained that a DSC clause "... exists precisely in order to 'take at least some of the gamble on subsurface conditions out of bidding': instead of requiring high prices that must insure against the risks inherent in unavoidably limited pre-bid knowledge, the provision allows the parties to deal with actual subsurface conditions once, when work begins, 'more accurate' information about them can reasonably be uncovered. For that reason, even requirements for pre-bid inspection by the contractor have been interpreted cautiously regarding conditions that are hard to identify accurately before work begins, so that 'the duty to make an inspection of the site does not negate the changed conditions clause by putting the contractor at peril to discover hidden subsurface conditions or those beyond the limits of an inspection appropriate to the time available'."9

Similarly, the Court in Foster Construction C.A. v. United States, held that "[e]ven unmistakable contract language in which the Government seeks to disclaim responsibility for drill hole data does not lessen the right of reliance. The decisions reject, as in conflict with the changed conditions clause, a 'standard mandatory clause of broad application,' the variety of such disclaimers of responsibility – that the logs are not guaranteed, not representations, that the bidder is urged to draw their own conclusions."10

The analysis undertaken by the courts in Metcalf and Foster will not apply if the owner includes an avoidance clause in a contract without a DSC clause.  In such an event, a court should enforce the avoidance clause as written, so long as it is clear and unambiguous, and not unlawful or a violation of public policy.

In sum, contractors should carefully review DSC, site inspection, and avoidance clauses in their contracts, attend pre-bid meetings, and review all information that is either provided or made available to the contractor before submitting a bid, or they run the risk that they may be responsible for DSCs.


1  Unforeseen hazardous materials could be considered a third category of DSC, as most form contracts treat the discovery of hazardous materials different from the discovery of a Type 1 or Type 2 DSC.  See, e.g., AIA Document A201-2007, §10.3; ConsensusDocs 200-2011 (revised July 2012), §3.13; DBIA Document no. 535-201, §4.1; EJCDC Document C-700-2013, §5.06.

2 Section 3.2.1, AIA Document A201-2007.

3 See, e.g., Robert E. McKee, Inc. v. City of Atlanta, 414 F. Supp. 957 (N.D. Ga. 1976) (bidder did not have sufficient time or access to conduct an adequate inspection); W.F. MaGann Corp. v. Diamond Mftg. Co., Inc., 580 F. Supp. 1299, 1313-14 (1984) (insufficient time to perform inspection).

4  736 P.2d 140 (OK 1987)

5 40 Fed. Cl. 184.

Stuyvesant Dredging Co. v. United States, 834 F.2d 1576, 1581 (Fed. Cir. 1987)

7 See, e.g., Top Painting Co., Inc., ASBCA No. 57333, 12-1 BCA 35,020 (2012) (contractor denied recovery for a differing site condition to paint certain equipment because a site visit would have disclosed that substantial prep work was required); D&M Grading, Inc. v. Dept. of Agriculture, CBCA No. 2625, 12-1 BCA 35,021 (2012) (contractor denied recovery for a DSC claim because a site visit would have indicated that the roads it was required to maintain were in poor shape); Orlosky, Inc. v. United States, 64 Fed. Cl. 63, (2005).

8 See, e.g., Metcalf Constr. Co., Inc. v. United States, 742 F.3d 984 (Fed. Cir. 2014).

9 Id. (citing Foster Const. C.A. & Williams Bros. Co. v. United States, 193 Ct.Cl. 587, 435 F.2d 873, 887-88 (Ct.Cl.1970)); H.B. Mac, Inc. v. United States, 153 F.3d 1338, 1343 (Fed.Cir.1998); Hollerbach v. United States, 233 U.S. 165, 170–71, 49 Ct.Cl. 686, 34 S.Ct. 553, 58 L.Ed. 898 (1914).

10 Foster Construction C.A. v. United States, 435 F.2d 873, 888 (Ct. Cl. 1970). See also Woodcrest Constr. Co. v. United States, 408 F.2d 395 (Ct. Cl. 1969) ("... broad exculpatory clauses... cannot be given their full literal reach, and, "do not relieve the defendant of liability for changed conditions as the broad language thereof would seem to indicate... General portions of the specifications should not lightly be read to override the Change Conditions Clause...").

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Similar Articles
Relevancy Powered by MondaqAI
In association with
Related Topics
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions