United States: Texas Supreme Court Limits The Enforceability Of No-Delay-Damages Provisions

The Texas Supreme Court held that a no-delay-damages provision cannot shield an owner from liability for deliberately and wrongfully interfering with a contractor's work. Zachry Constr. Corp. v. Port of Houston Auth., No. 12-0772, 2014 Tex. LEXIS 768, at *43 (Tex. Aug. 29, 2014). The court not only reaffirmed five exceptions to the enforceability of no-delay-damages provisions but also held that, as a matter of public policy, such provisions cannot be enforced—regardless of what the contract states—if the delay resulted from the owner's deliberate, intentional, and wrongful conduct, which may include instances where an owner's decision results in the increased delays.

The Zachry opinion may aid contractors seeking to avoid the effect of no-delay-damages provisions in the face of actions by an owner, and serves as a warning to owners that reliance on contractual provisions is not a foolproof defense where the owner plays an active role in project management decisions that result in longer time periods and higher costs.

Background

Zachry Construction Corporation ("Zachry") and the Port of Houston Authority of Harris County ("the Port") entered into a contract for Zachry to construct a wharf on the Bayport Ship Channel. The Port set a two-year completion schedule. To accommodate the Port's aggressive timetable, Zachry developed a plan using soil dredged from the channel to construct an eight-foot-wide earthen berm and form a wall around the future construction area. Zachry installed a refrigerated pipe system in the wall delivering super-cooled brine, freezing the wall and keeping the work area clear and dry.

Nine months into the project, the Port sought to increase the size of the wharf by 332 feet. Zachry proposed building another freeze wall to complete the additional construction under dry conditions, but the Port apparently had concerns that this plan might destabilize piers near the construction site. The Port, however, did not raise its concerns with Zachry at the time, and a change order was then issued based on Zachry's plan.

Two weeks later, the Port ordered Zachry to resubmit a plan without the freeze wall. Zachry attempted to dispute this directive, but the Port refused to negotiate. Zachry finished the original section of the wharf, removed the freeze wall, and continued work on the additional 332-foot extension. The completion of the additional section without the aid of the freeze wall took substantially longer, which resulted in the Port withholding a total of $2.36 million in liquidated damages from Zachry's payments. Zachry eventually completed the project more than two and a half years after the contract deadline.

Zachry filed suit claiming approximately $30 million in damages from the delays caused by the Port. The Port pointed to the contract, which precluded delay damages. The no-delay-damages provision stated in part:

  • Zachry or any of its subcontractors or suppliers shall receive no financial compensation for delay or hindrance to the Work, regardless of the source of the delay;
  • Zachry was not entitled to financial compensation even if the source of the delay resulted from events of force majeure or the negligence, breach of contract, or other fault of the Port; and
  • Zachry's sole remedy shall be an extension of time.

See Zachry, No. 12-0772, 2014 Tex. LEXIS 768, at *8. Zachry successfully argued that the Port's intentional actions rendered this clause unenforceable. After a three-month trial, the jury found that (i) the Port breached the contract by rejecting Zachry's freeze wall design, resulting in $18,602,697 in delay damages, and (ii) the delay was the result of the Port's arbitrary and capricious conduct, active interference, bad faith, and fraud.

Enforceability of the No-Delay-Damages Provision

In general, a contractor may agree to assume the risk of construction delays and not seek damages under Texas law. Nevertheless, there are five recognized exceptions to this rule — where the delay: (i) was not intended or contemplated by the parties to be within the purview of the provision; (ii) resulted from fraud, misrepresentation, or other bad faith on the part of one seeking the benefit of the provision; (iii) has extended for such an unreasonable length of time that the party delayed would have been justified in abandoning the contract; (iv) is not within the specifically enumerated delays to which the clause applies; and (v) was based upon active interference with the contractor or other wrongful conduct, including arbitrary and capricious acts, willful and unreasoning actions, without due consideration and in disregard of the rights of other parties.1

Here, while Zachry argued that the second and fifth exceptions applied and the jury agreed, the court of appeals held that, even if the Port's conduct fell within an exception, the "other fault" language in the no-delay-damages provision was intended to cover the kind of misconduct by the Port found by the jury. The Texas Supreme Court rejected this conclusion for two reasons.

First, as a matter of textual interpretation, the court doubted whether "other fault" was intended to include the kind of deliberate, wrongful conduct in which the Port engaged. The court of appeals' interpretation was particularly flawed, according to the supreme court, in light of the purpose of no-delay-damages provisions. Specifically, experienced contractors can assess potential delaying events when estimating and bidding public works, but they cannot assess potential delays that may arise due to an owner's direct interference, willful acts, negligence, bad faith fraudulent acts, or omissions. See Zachry, No. 12-0772, 2014 Tex. LEXIS 768, at *40-41.

Second, a contractual provision exempting a party from contract liability for harm caused intentionally or recklessly is typically unenforceable on public policy grounds. The court found this case consistent with cases where pre-injury waivers of future liability for gross negligence are void as against public policy. The court noted that its conclusion was supported by lower courts in Texas and 28 other U.S. jurisdictions. See Zachry, No. 12-0772, 2014 Tex. LEXIS 768, at *41-44.

Further, while the Port argued that the cases in other jurisdictions were distinguishable because those jurisdictions recognize a party's duty of good faith in performing a contract and Texas does not, the court flatly rejected this argument. The "law need not impose a duty of good faith on a party to prohibit him from attempting to escape liability for his future, deliberate, wrongful conduct." Zachry, No. 12-0772, 2014 Tex. LEXIS 768, at *43. The Port also maintained that failing to enforce a no-delay-damages provision is in derogation of the freedom to contract and that Zachry was a sophisticated company. But, the court found that a contractual provision can violate public policy and "the law's protection against intentional injury is not limited to the helpless." Id.

Implications for Contractors and Owners

At bottom, the Texas Supreme Court affirmed that while parties are generally free to draft their contracts as they see fit, they cannot immunize themselves from deliberate and wrongful conduct. The extension of this rule outside of tort liability and into the construction context is important for both owners and contractors.

For contractors, the decision gives teeth to the recognized exceptions involving no-delay-damages provisions in Texas. Notably, several of these exceptions likely raise fact issues that may be difficult to defeat on summary judgment. For example, a Texas state court may have difficulty deciding as a matter of law whether an owner engaged in "willful and unreasoning actions" or "arbitrary and capricious acts." Savvy plaintiff's lawyers may be able to create triable issues of fact that otherwise may have been disposed of on summary judgment.

For owners, they need to be tuned in to all of these factors and their involvement in the project, not only during contract negotiations, but also throughout the course of the engagement. For example, if there is a scope of work change, owners need to be upfront with any concerns and careful in how they approach further changes that increase time and expenses. In short, to attempt to protect themselves, owners need to think about ways their decisions and conduct may arguably fit into one of the five exceptions and render the no-delay-damages provision unenforceable.

Conclusion

The court's decision highlights the need for owners to monitor their own conduct throughout a project and the potential for additional remedies for contractors where an owner actively drives a project in a direction that ultimately requires additional time and money.

Footnote

1. See, e.g., Green Int'l, Inc. v. Solis, 951 S.W.2d 384, 387 (Tex. 1997); Shintech Inc. v. Group Constructors, Inc., 688 S.W.2d 144, 148 (Tex. App.—Houston [14th Dist.] 1985, no writ); City of Houston v. R.F. Ball Constr. Co., 570 S.W.2d 75, 80 (Tex. Civ. App.—Houston [14th Dist.] 1978, writ ref'd n.r.e.).

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Andrew D. Ness
William R. Taylor
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions