UK: Legal Developments In Construction Law - September 2018

Last Updated: 28 September 2018
Article by Mayer Brown

1. Supreme Court rules bank owes no duty of care for gambler's credit reference

A bank was asked to provide a credit reference in respect of a customer. The request came from Burlington Street Services Ltd, a company acting for the Playboy Club, but the true purpose of the inquiry, and the fact that the reference was required for the benefit of another company was not disclosed. The bank confirmed that the customer had an account with them and was trustworthy up to £1.6 million per week but the account was not opened until two days after the reference was sent and had a nil balance until it was closed two months later. The Club was left with losses when the customer's cheques were returned unpaid and sued the bank, claiming that the bank owed it a duty of care in giving the reference.

The Court of Appeal said the only party owed a duty of care was Burlington but the Club appealed to the Supreme Court, claiming that it was owed a duty of care because, borrowing the contract law agency concept, it was Burlington's undisclosed principal.

In rejecting the Club's appeal the Court said that it does not follow from the fact that a non-contractual relationship between two parties is as proximate as a contractual relationship, that it is legally the same as a contractual relationship or involves all of the same legal incidents. Whether a relationship is sufficiently proximate to give rise to a duty of care is essentially a question of fact from which the law draws certain conclusions. The liability of a contracting party to its counterparty's undisclosed principal, however, is not a legal conclusion from any factual relationship between them. A person may be brought into contractual relations with someone with whom they have no factual relationship at all. Such a relationship is by definition not proximate nor, in any relevant sense, voluntary or consensual so as to give rise to an assumption of responsibility. And the law on undisclosed principals is a complex bundle of interrelated rights and liabilities, most of which are entirely inapposite to tort law.

The Bank had no reason to suppose that Burlington was acting for someone else, and they knew nothing of the Club. In those circumstances, it was plain that they did not voluntarily assume any responsibility to the Club.

Banca Nazionale del Lavoro SPA v Playboy Club London Ltd & Ors [2018] UKSC 43

2. Court of Appeal confirms contract clause bars eot for concurrent delay

A building contract clause said that, where there was a delay for which the contractor was responsible, concurrent with a delay for which the employer was responsible, the employer delay would not be taken into account in calculating any extension of time. But was the clause contrary to the 'prevention principle' and therefore ineffective, as the contractor claimed?

On appeal, the Court of Appeal confirmed that the clause was effective. It was unambiguous and clearly sought to allocate the risk of concurrent delay to the contractor. The prevention principle is not an overriding rule of public or legal policy but operates by way of implied terms; it was not applicable in the case and had no obvious connection with the separate issues that might arise from concurrent delay. The clause was designed to do no more than reverse the result in the Malmaison Hotel and Walter Lilly cases for this particular contract and, perhaps most important, it was an agreed term and there is no suggestion in the cases considered that the parties could not contract out of some, or all, of the effects of the prevention principle; in fact the contrary was the case. The contractor also claimed that, even if the clause was enforceable, there was an implied term that would prevent the employer from levying liquidated damages, because the damages did not f low from a delay for which the contractor was responsible. This argument also failed. There was a proper causal link between the delay and the liquidated damages, the extension of time provisions were inextricably linked to the liquidated damages provisions and any implied term which sought to take away the employer's entitlement to liquidated damages for concurrent delay would be contrary to the express contract terms. A term cannot be implied if it contradicts express terms. Additionally, any such implied term would not go without saying and pass the 'officious bystander' test and would not be required to make the contract work, in accordance with the 'business efficacy' test. The result was not, in any way, uncommercial or unreal. A period of concurrent delay, properly

so-called, arises because a delay has occurred for two separate reasons, one being the responsibility of the contractor and one the responsibility of the employer. Each can argue that it would be wrong for the other to benefit from a period of delay for which the other is equally responsible. Either result may be regarded as harsh on the other party but neither could be said to be uncommercial or unworkable.

An issue that the court did not decide was whether, where there is concurrent delay, it could, or could not, be said that the employer had actually delayed the contractor at all.

North Midland Building Ltd v Cyden Homes Ltd [2018[ EWCA Civ 1744

3. Failure to obtain assignment of engineer's report sinks duty of care claim

Consulting engineers prepared a site investigation report for the vendors of a site in South Wales. The report stated that it was for the vendor's use and should not be passed on to others without the consultant's express consent, but that it could be assigned to the eventual site purchaser. The consultant's contract with the vendor also contained a third party rights exclusion and caps on liability. The vendor disclosed the report to the purchaser but its benefit was never assigned and there was therefore no contract between the consultant and the purchaser. But did the consultant owe the purchaser a duty of care in tort?

The court noted some relevant key principles from case law; that it is always necessary to consider the circumstances and context, commercial, contractual and factual, including the contractual structure, in which the parties' inter-relationship arises. Not every careless misstatement is actionable or gives rise to a duty of care. Foreseeability of loss is not enough (by itself). It is necessary to establish that the duty relates to the kind of loss suffered and to determine the scope of any duty of care, again considering the context and circumstances. Disclaimers are simply one factor, but possibly an important one, in determining whether a duty of care arises. Telling everyone concerned that you are not accepting a responsibility is usually inconsistent with voluntarily undertaking it. In finding that no duty of care was owed in tort, the court said that the no use, no passing on and assignment statements in the report, when read in the context of the contract containing the third party rights exclusion and the liability limitation, made it reasonably clear, on an objective assessment, to the purchaser that, if it wanted to place legal reliance on the report, it would have to obtain an assignment or other legal document from the consultant to do so.

BDW Trading Ltd v Integral Geotechnique (Wales) Ltd [2018] EWHC 1915

4. New government consultation on amended Building Regs fire safety guidance

The government is seeking views on the improved clarity and usability of new draft guidance on fire safety in Building Regulations Approved Document B, following recommendations made by Dame Judith Hackitt. The clarified draft contains revised guidance on restricting the use of assessments in lieu of tests and the use of combustible materials in the external walls of high-rise buildings, both the subject of separate consultation.

The government is to produce a detailed impact assessment based on the information received from the consultation to inform its final policy decision.

The consultation closes on 11 October 2018.

The Secretary of State for Communities has also said that he will conduct a full-scale review of the Approved Document B guidelines, commencing in the autumn. The technical review will assess, amongst other things, whether the underlying policy should be updated to reflect modern building practice, the latest understanding of fire risks and technical and scientific innovations. brokenshire-moves-to-review-building-regulations- fire-safety-guidance?utm_source=93f2acf4-8cda- 4846-929e-6d2e2bc5e5a2&utm_ medium=email&utm_campaign=govuk- notifications&utm_content=immediate

5 Revised NPPF published

The government has published the revised National Planning Policy Framework, setting out its planning policies for England and how these are expected to be applied, and replacing the previous version of the NPPF, published in March 2012.

See: planning-rulebook-to-deliver-more-quality-well-designed- homes?utm_source=5c5e8622-3dcb-4c68-8db8- a0c0325fe0f0&utm_medium=email&utm_ campaign=govuk-notifications&utm_content=immediate

6. Government plans new measures on insolvency and corporate governance

The government has published its response to the consultation on insolvency and corporate governance. The document sets out its proposed next steps; in some areas the government will legislate but in other areas further consultation will be needed.

The proposed insolvency reforms include

  • the introduction of a new moratorium to give ultimately viable financially distressed companies a period of time when creditors (including secured creditors) cannot take action against the company, allowing it to make preparations to restructure or seek new investment;
  • prohibition of enforcement by a supplier of termination clauses in contracts for supply of goods and services, on the grounds that a party has entered a formal insolvency procedure, the new moratorium or the new restructuring plan; and
  • creation of a new restructuring vehicle that would include the ability to bind dissenting classes of creditors who vote against it.

See: to-improve-rescue-opportunities-for-financially- distressed-companies and uploads/system/uploads/attachment_data/file/736163/ ICG_-Government_response_doc_-24_Aug_clean_ version__with_Minister_s_photo_and_signature__ AC.pdf

Visit us at

Mayer Brown is a global legal services provider comprising legal practices that are separate entities (the "Mayer Brown Practices"). The Mayer Brown Practices are: Mayer Brown LLP and Mayer Brown Europe – Brussels LLP, both limited liability partnerships established in Illinois USA; Mayer Brown International LLP, a limited liability partnership incorporated in England and Wales (authorized and regulated by the Solicitors Regulation Authority and registered in England and Wales number OC 303359); Mayer Brown, a SELAS established in France; Mayer Brown JSM, a Hong Kong partnership and its associated entities in Asia; and Tauil & Chequer Advogados, a Brazilian law partnership with which Mayer Brown is associated. "Mayer Brown" and the Mayer Brown logo are the trademarks of the Mayer Brown Practices in their respective jurisdictions.

© Copyright 2018. The Mayer Brown Practices. All rights reserved.

This Mayer Brown article provides information and comments on legal issues and developments of interest. The foregoing is not a comprehensive treatment of the subject matter covered and is not intended to provide legal advice. Readers should seek specific legal advice before taking any action with respect to the matters discussed herein.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions