UK: Construction Case Comment – Adjudicating When The Contract Works As A Whole Are Excluded Operations?

Last Updated: 6 March 2018
Article by James Grinstead

The Technology and Construction Court (TCC) has recently issued guidance on what activities are excluded from the statutory adjudication process under s.105(2) of the Housing Grants (Construction and Regeneration) Act 1996 as amended under the Local Democracy Economic Development and Construction Act 2009 (the "Construction Act") and on what basis a court may order a 'stay of execution' against a victorious SPV claimant.

Case summary (Equitix ESI CHP (Wrexham) Limited v Bester Generacion UK Limited)

This case concerned a project to design and build the Wrexham Biomass Fired Energy Generating Plant (the "Project"). The claimant was a special purpose vehicle ("SPV") created for the Project, whilst the defendant was the main contractor. The dispute was focused on the validity of the claimant's termination of the contract and the basis for claiming back substantial sums already paid to the defendant.

Progress on the Project was slow and the employer issued a notice of adjudication to obtain a declaration that the defendant was not entitled to an extension of time. The adjudicator agreed and so the claimant subsequently terminated the contract, stating to the defendant that it had opted not to continue with the Project.

Following the termination of the contract the claimant issued an interim account requiring the defendant to pay around £11.5m.

The dispute arose around whether the contract was validly terminated and the valuation of the interim account (£11.5m). The dispute was referred by the claimant to the same adjudicator as the initial adjudication (for the extension of time point) who decided the defendant was liable to pay approx. £9.8m to the claimant. Proceedings were subsequently brought by the claimant in the TCC, to enforce that second adjudication decision.

What is classed as a construction contract dispute?

The Construction Act applies to 'construction operations' and defines construction operations by listing a wide range of matters which constitute construction operations (as per s.105(1) of the Act) – for full details of what is included within the ambit of the Act, please click on the above link.

The Construction Act also excludes certain works from construction operations (s.105(2)). Excluded operations (under s.105(2)(c) of the Act) include:

"assembly, installation or demolition of plant, machinery, or erection or demolition of steelwork for the purposes of supporting or providing access to plant or machinery, on a site where the primary activity is:

(i) nuclear processing, power generation or water or effluent treatment..."

S.104(5) of the Construction Act also provides that if a contract relates to construction operations and other matters (construed as a "hybrid contract") the Act applies only so far as it relates to construction operations.

In this case the defendant's main argument was that s.105(2) of the Construction Act excluded the construction operations being carried out by the defendant contractor and that the payments made by the claimant to the defendant involved payments for excluded activities. In essence it resisted enforcement on the basis that the adjudicator did not have jurisdiction to determine the dispute.

The claimant argued that the payments were in fact made for activities permitted under s.105(1) of the Act (and not excluded by s.105(2)(c) of the Act). On the latter point, it cited that the ground in question had not been excavated (in preparation for the contracted works to be commenced and then did not fall within the assembly, installation or demolition exclusion). Mr Justice Coulson agreed with this assessment and confirmed that the works carried out by the defendant until the point of termination fell within the scope of s.105(1)(e) of the Act and so no jurisdiction issue arose in respect of the adjudication. Preparation works are common in major construction projects and in this case, because no plant had ever been brought on-site by the defendant (as per s.105(2)(c)) the dispute did not concern excluded activities under the Act.

Mr Justice Coulson went on to state that the defendant was focussing its case on the Project as a whole, rather than the dispute which had actually been referred in the second adjudication. What matters is not whether the project taken as a whole is considered to be an excluded activity, but whether any part of the dispute concerned excluded operations – which could be deemed to be a hybrid contract (s.104(5)) and so subject to the Construction Act.

Having found that the adjudicator did have jurisdiction, the court provided additional guidance in respect of making general reservations about an adjudicator's jurisdiction. Such reservations need to be made early and need to be explicitly and unequivocally clear for a party to rely on that reservation later down the line. One cannot rely on a general reservation or grievance on the basis it tallies with a point stemming from a previous adjudication associated with the same matter and/or parties.

Notwithstanding the adjudication and jurisdiction aspects mentioned above, Mr Justice Coulson only enforced part of the adjudicator's decision (£4.5m of the £9.8m awarded to the claimant) – a "stay of execution", as the claimant was a SPV and no longer had a purpose. This is significant as once the payment of the sums awarded had been completed, the SPV would be wound down with no way of recovering any sums due if applicable.

This case confirms the courts' approach to the interpretation of "construction operations" under the Act, with s.105(1) being interpreted broadly and the exceptions under s.105(2) being interpreted narrowly. The idea that the broad purpose of a contract is ignored when determining whether aspects of a specific dispute concern excluded activities is consistent with Cleveland Bridge (UK) Limited v Whessoe-Volker Stevin Joint Venture [2010] where Ramsay J held that fabrication drawings and off-site fabrication or delivery to site were not excluded activities within the wording of s.105(2)(c).

It is therefore essential to consider whether the construction operation is excluded or not when considering whether or not to bring an action against another party. This is because the basis for a construction contract dispute may seem quite clear cut on the face of it, but may not be so clear cut if the construction operations you are contracted to fulfil are excluded works and so precluded from adjudication or other proceedings in the courts.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions