UK: A Cold Wind Blows: The Impact Of A More Literal Approach To Contractual Interpretation On Construction Contracts

Last Updated: 11 August 2017
Article by Claire King

The key to resolving disputes is all too often working out what a particular provision or provisions actually means. Parties may have wildly different views on what something means even after spending hours negotiating the fine print and signing on the dotted line.

In the last few years the Supreme Court has signalled a distinct change of approach from the judiciary with regard to contractual interpretation. Instead of looking at the "surrounding circumstances" and "commercial common sense" to interpret contractual provisions whose meaning is disputed, a series of judgments have underlined the primacy of language even where this results in a one-sided, unfair or even absurd result.1

In this Insight we look at the impact this has already had on the interpretation of construction contracts. We then ask what in particular those negotiating and drafting construction contracts should be aware of in light of this change of approach.

Contractual interpretation over the last 30 years

Interpretation has been defined as ascertaining the meaning that a contractual document would convey to a reasonable person, but what this means in practice is by no means straightforward.2

Over the past 30 years, two threads of case law have moved the rules on interpreting contracts away from looking primarily at the literal meaning of the words themselves.  The first thread opened the door to looking at the surrounding circumstances in which the contract was agreed.3 The second used "commercial common sense" to allow a more sensible, and potentially less harsh, interpretation of the words in dispute.

The first three principles in the famous House of Lords case, Investors Compensation Scheme Ltd v West Bromwich Building Society,4 were recently described as broadening:

"the range of facts which could serve as relevant surrounding circumstances, so as to include 'absolutely anything' which would have affected the way in which the contract would have been understood by a reasonable man apart from pre-contractual negotiations and information unavailable to the parties."5

Further, the suggestion was that if something had gone wrong with the words in the contract the law may attribute a different intention to them.6

The idea of interpreting contracts in line with "commercial common sense" began to appear in the early 1990s.  In Mannai Investment Co. Ltd v Eagle Star Life Assurance7 Lord Steyn stated:

"Words are therefore interpreted in the way in which a reasonable commercial person would construe them. And the standard of the reasonable commercial person is hostile to technical interpretations and undue emphasis on niceties of language." [Emphasis added]

For those seeking to wriggle out of an unduly harsh result, the attractions of such an approach are obvious: "If there are two possible constructions, the court is entitled to prefer the construction which is consistent with business common sense and to reject the other." 8

The cold wind: a more literal approach

In the last couple of years, however, there has been a return to a more literal interpretation of contracts, even where that results in a harsh result. Although it has been described by some as being carried out in "muffled tones",9 the trend has been widely recognised.

The key case sounding the retreat is the Supreme Court case of Arnold v Britton.10  Lord Neuberger emphasised seven principles the last of which is not widely applicable to construction contracts.  The six relevant principles were:

  1. "reliance placed on commercial common sense and surrounding circumstances ...  should not be invoked to undervalue the importance of the language of the provision which is to be construed";
  2. "when it comes to considering the centrally relevant words to be interpreted, I accept that the less clear they are, or, to put it another way, the worse their drafting, the more ready the court can properly depart from their natural meaning";
  3. "commercial common sense is not to be invoked retrospectively"
  4. "while commercial common sense is a very important factor to take into account when interpreting a contract, a court should be very slow to reject the natural meaning of a provision as correct simply because it appears to be a very imprudent term for one of the parties to have agreed, ignoring the benefit of wisdom of hindsight"
  5. "When interpreting a contractual provision, one can only take into account facts or circumstances which existed at the time that the contract was made, and which were known or reasonably available to both parties"; and
  6. "in some cases, an event subsequently occurs which was plainly not intended or contemplated by the parties, judging from the language of their own contract. In such a case, if it is clear what the parties would have intended, the court will give effect to that intention." 

What is the rationale behind this change of approach?  The underlying reasoning is to give parties greater certainty that the literal words they have written will be upheld. As Lord Sumption has suggested:

"[It is] time to reassert the primacy of language in the interpretation of contracts. It is true that language is a flexible instrument. But let us not overstate its flexibility. Language, properly used, should speak for itself and it usually does. The more precise the words used and the more elaborate the drafting, the less likely it is that the surrounding circumstances will add anything useful." [Emphasis added]

Certainly in Arnold v Britton the result was very harsh on those who were subject to the leases at the heart of the dispute.  They ended up being liable to pay a huge amount of rent which was, on anyone's interpretation, a harsh result given that the properties in question were chalets on a leisure park on the Gower Peninsula. It is also plain that the debate continues, with the Supreme Court, in Wood v Capita Insurance Services Limited,11 denying that Arnold v Britton marked a shift away from the Rainy Sky position.

So what does this all mean in practice?

Well the impact has already been seen in the context of both payment terms and extension of time provisions. What is clear is that what has sometimes been used as a "get out of jail card" (i.e. arguing business common sense to escape an otherwise harsh result) is going to be an increasingly hard card to use in the future.

Payment terms

Arnold v Britton was applied in the case of Balfour Beatty Regional Construction Ltd v Grove Developments Ltd,12 which concerned interim payments under the JCT contract.  Within the contract was a payment schedule which stipulated the precise dates for payment.  However, these only scheduled payments until July 2015 and the works ran past that point by a substantial period of time.

The Court of Appeal held that on a proper construction of the contract and the payment schedule, there should be no interim payments after the contractual date for completion, i.e. July 2015.

Balfour Beatty took account of Arnold v Britton and Lord Neuberger's seven principles (listed above). Counsel drew the Court's attention particularly to Lord Neuberger's fourth principle on commercial common sense.  Relying on that, Jackson LJ stated:

"Commercial common sense can only come to the rescue of a contracting party if it is clear in all the circumstances what the parties intended, or would have intended, to happen in the circumstances which subsequently arose."13

The lesson is clear – pay attention to the literal meaning of what you have written down. Commercial common sense will not come to the rescue if the meaning of a provision is clear, however harsh the result is.  More specifically on payment provisions, check there is an express provision for payments to continue past the planned completion date for the works.

Extension of time provisions

Similarly, in the Court of Appeal case of Carillion Construction Ltd v Woods Bagot Europe Ltd,14 Arnold v Britton was cited in order to justify a literal interpretation of the extension of time provisions within a JCT subcontract. The contract in question was based on the DOM/2 form, 1981 edition.

During the hearing of preliminary issues, the Court was asked whether, assuming that Emcor (a subcontractor) was entitled to an extension of time, that extension should:

  1. run contiguously from the end of the current period for completion to provide an aggregate period within which Emcor's works should be completed; or
  2. fix further periods in which Emcor could undertake their works, which were not necessarily contiguous but reflected the period for which it had been delayed.

Clause 11.3 provided as follows:

"11.3 If on receipt of any notice, particulars and estimate under clause 11.2 the Contractor properly considers that:

.1 any of the causes of the delay is an act, omission or default of the Contractor, his servants or agents or his sub-contractors, their servants or agents (other than the Sub-Contractor, his servants or agents) or is the occurrence of a Relevant Event; and

.2 the completion of the Sub-Contract Works is likely to be delayed thereby beyond the period or periods stated in the Appendix, part 4, or any revised such period or periods,

then the Contractor shall, in writing, give an extension of time to the Sub-Contractor by fixing such revised or further revised period or periods for the completion of the Sub-Contract Works as the Contractor then estimates to be reasonable."

The Judge held that the natural meaning of the words used of the subcontract conditions, when read in context, was that any period of extension granted will be added contiguously to the end of the current period within which the subcontractor is required to complete its works. The Court of Appeal agreed. They accepted that there may be situations in which clause 11.3 may lead to an unsatisfactory result. For example it could exempt a subcontractor from liability during a period when it was in culpable delay, or render the subcontractor liable to the contractor for a period when it was not in culpable delay. However, clause 11.3 was practicable, workable and accorded with commercial common sense.

At paragraph 46 of the judgment, Jackson LJ notes:

"Recent case law establishes that only in exceptional circumstances can considerations of commercial common sense drive the court to depart from the natural meaning of contractual provisions. See Arnold at [19] and [20]. In Grove the Court of Appeal applied those principles to a construction contract, which operated harshly against the interests of a contractor. The court declined to depart from the natural meaning of the contractual provisions." [Emphasis added]

Conclusion

A shift away from the, arguably, more lenient interpretation of rules over the previous 30 years appears to be under way.  The exact scope and nature of this shift is still being debated and ascertained.  Indeed, Lord Hodge did not accept that there had been a "recalibration" in a recent Supreme Court case in contrast to Lord Sumption's view.15

However, in the author's view there does indeed appear to be a trend towards a more literal interpretation of contracts.  The impact of this has already been seen in two Court of Appeal cases on the interpretation of construction contracts.  For those negotiating contracts the message is clear: don't rely on the courts to get you out of a hole by relying on commercial common sense.  Ask yourself what the literal meaning of your words is and check you are happy with the answer, including, most importantly, if the contract doesn't proceed as planned.

With thanks to Laura Bowler for her research on assistance


  • 1. See Arnold v Britton [2015] AC 169; and Krys v KBC Partners [2015] UKPC 46 by way of example. For detailed discussion on this shift see Lord Sumption's paper "A Question of Taste: The Supreme Court and the Interpretation of Contracts" delivered at the Harris Society Annual Lecture at Keble College, Oxford.
  • 2. Investors Compensation Scheme Ltd v West Bromwich Building Society [1998] 1 WLR 896 at 912.
  • 3. As per Lord Hoffman in Investors Compensation Scheme Ltd v West Bromwich Building Society [1998] 1 WLR 896 at 912. In that House of Lords judgment, interpretation was defined as being "the ascertainment of the meaning which the document would convey to a reasonable person having all background knowledge which would reasonably have been available to the parties in the situation in which they were at the time of the contract" [emphasis added]. See Lord Sumption's speech dated 8 May 2017 made at the Harris Society Annual Lecture, Keble College, Oxford, entitled "A Question of Taste: The Supreme Court and the Interpretation of Contracts".
  • 4. [1998] 1 WLR.
  • 5. See page 6 of Lord Sumption's Harris Society Annual Lecture.
  • 6. See page 7 of Lord Sumption's Harris Society Annual Lecture.
  • 7. [1997] UKHL 19.
  • 8. Rainy Sky S.A. v Kookmin Bank [2011] 1 WLR 2100, paragraph 21.
  • 9. See Lord Sumption's Harris Society Annual Lecture, page 13.
  • 10. [2015] UKSC 36.
  • 11. [2017] UKSC 24.
  • 12. [2016] EWCA Civ 990.
  • 13. See Balfour Beatty Regional Construction Ltd v Grove Developments Ltd  [2016] EWCA Civ 990 at para 41.
  • 14. [2017] EWCA Civ 65.
  • 15. [16] See Wood v Capita Insurance Services Limited [2017] UKSC24 at paragraph 9. In Arnold v Britton, something Lord Sumption would presumably disagree with.

Please click here to view previous issues of Insight

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Claire King
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.