UK: Fact Over Forecast In Construction Contracts

Last Updated: 23 June 2017
Article by Mike Barlow

How Often Do We Check The Weather Forecast, While Sitting Beside A Window? Why Do We Rely On Forecasts When Facts Are So Frequently Staring At Us? The Northern Irish High Court Was Recently Faced With This Conundrum In Northern Ireland Housing Executive V Healthy Buildings (Ireland) Limited. The High Court Analysed The Assessment Of Compensation Events Under The Professional Services Contract That Forms Part Of The NEC3 Suite Of Construction Contracts.  NEC3 Is A Popular Form Of Construction Contract Used Both In The UK And Internationally To Procure Major Projects.

The Court Determined That The Assessment Of The Financial Effect Of A Compensation Event Under NEC3, Where The Effects Were Known, Ought To Be Calculated By Reference To The Actual Cost Incurred, Rather Than A Forecast. This Helps To Clear Up Some Uncertainty As To How NEC3's Compensation Event Regime – Which Generally Aims To Resolve Compensation Events On A Prospective, As Opposed To A Retrospective, Basis – Should Operate When The Assessment Takes Place After The Actual Effects Of A Compensation Event Have Become Known.  Whilst NEC3's Successor, NEC4, Will Make Its Debut Later This Month, On 22 June 2017, The Compensation Provisions Remain Largely The Same Across Both Versions. The Court's Decision Is Therefore Likely To Have Far-Reaching Effects.

What Happened?

Northern Ireland Housing Executive ("The Employer") Employed Healthy Buildings (Ireland) Limited ("The Consultant") To Carry Out Asbestos-Related Assessments In Certain Buildings. The Contracts Were NEC3 Professional Services Contracts ("The Contract").

After Entering Into The Contract, The Employer Changed The Scope Of The Services Without Specifically Notifying That Change To The Consultant As A Compensation Event. In Terms Of The Contract, The Employer Ought To Have Notified The Consultant Of The Compensation Event And To Have Invited The Consultant To Submit A Quotation Assessing The Effects Of The Compensation Event. In Any Event, The Consultant Later Submitted Quotations Which Were Subsequently Rejected By The Employer, Who Assessed The Effect Of The Compensation Event As Zero.

The Matter Was Referred To Adjudication Which Found In Favour Of The Consultant. The Employer Paid Up, Only To Later Challenge The Adjudicator's Decision In The Northern Irish Courts, Demanding Repayment.  The Consultant Counterclaimed For Additional Monies Over And Above Those Awarded By The Adjudicator.

Clause 63.1 Of The Contract Required The Financial Impact Of Compensation Events To Be Assessed With Reference To (1) The Actual Time Charge For Work Already Done And (2) The Forecast Time Charge For Work Not Yet Done.  The Consultant Defended The Court Action On The Basis That Under Clause 63.1, The Date When The Employer Instructed Or Should Have Instructed The Consultant To Submit Quotations Divided The Work Already Done From The Work Not Yet Done. The Consultant's Position Was That Although Its Quotation Was Submitted After The Employer Ought To Have Requested It, The Consultant's Quotation Should Nevertheless Have Been In The Form Of A Forecast, Not Based On An Actual Time Charge – Because At The Time When The Employer Should Have Instructed The Consultant To Submit A Quotation, The Work Had Not Yet Been Done (So There Was No Actual Time Charge).

The Court Was Asked To Determine, In This Situation:

  1. Whether The Assessment Of The Effect Of The Compensation Event Should Have Been Calculated By Reference To Actual Costs Incurred, Instead Of A Forecast Time Charge?
  2. Whether The Actual Costs Were Relevant To The Assessment Process Under The NEC3 PSC?

Fact V Forecast

The Court Answered "Yes" To Both (A) And (B), Describing Reliance On The Forecast As Being "Strained And Unnatural" And "Groping In The Dark", In A Situation Where The Facts Were Now Available.  The Court Opted For An Interpretation Of The Contract That, In Its View, Was "Consistent With Business Common Sense". The Court Requested The Consultant To Make Available All Documents Relating To Its Actual Costs, In Order To Assess The Financial Impact Of The Compensation Event.

In Favouring The Facts Over A Forecast, The Court Considered The Leading Authority On NEC3, Keating On NEC3, 2012. At Paragraph 7-109, Keating Comments That Assessment Of Compensation Events "Suggests An Idea Of Appraisal Or Judgment".  The Court Applied This Authority To The Facts Of The Present Case And Noted That Where A Quotation Is Provided After The Effect Of The Compensation Event Is Known, "[It] Ought To Be Informed By The Best Information Available As To The Actual Cost And Time Incurred By The Consultant As A Result Of The Instruction". In The Court's Opinion, This Interpretation Of The Contract Was "Efficacious And Business-Like".

Key Points

Although There Has Been At Least One Other Reported Case In Which The Prospective Versus Retrospective Question Was An Issue Between The Parties, This Decision Appears To Be The First Case In The UK To Specifically Address That Question (As Opposed To Being Decided On The Basis Of A Breach Of Natural Justice In The Context Of Adjudication Proceedings).  As Such, Northern Ireland Housing Executive V Healthy Buildings (Ireland) Limited Provides Some Much-Needed Clarity In Relation To The Assessment Of Compensation Events Under NEC3 (And NEC4), In A Situation Where The Parties Have Failed To Assess A Compensation Event At The Time It Occurred, Or Where The Assessment Is Disputed.  This Case Is However Unlikely To Be The Last Word On The Vitally Important Compensation Event Provisions Of NEC.  Employers May View The Case As Justification For Deliberately Delaying The Assessment Of Compensation Events In The Hope That Actual Costs, Calculated Retrospectively, Will Be Lower Than Forecast Costs, Calculated Prospectively.  That Approach Would Be Contrary To The Stated Aims Of NEC And Would Be Unlikely To Be Welcomed By At Least Some NEC Users.

This article was co-written by Shona McCusker. 

© MacRoberts 2017

Disclaimer

The material contained in this article is of the nature of general comment only and does not give advice on any particular matter. Recipients should not act on the basis of the information in this e-update without taking appropriate professional advice upon their own particular circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.