UK: Employer's Claims Under FIDIC Conditions Of Contract

Last Updated: 31 May 2016
Article by Kieran Fano

The recent Technology and Construction Court decision in J Murphy & Sons Ltd -v- Beckton Energy Ltd [2016] EWHC 607 (TCC) provides a useful illustration of the approach to Employer's claims under the FIDIC Conditions under English law.

The judgment will be of particular interest to users of the FIDIC suite who adopt English law as the applicable law and will be of wider interest to practitioners involved in advising and drafting specific amendments to standard form construction contracts. Moreover, the judgment serves as a reminder of the difficulties associated with restraining calls against 'on-demand'/performance bonds.

Background

The Employer, Beckton, entered into a contract with the Contractor, Murphy, for the design, construction, testing and commissioning of a power plant in East London. The Contract was based on the FIDIC Conditions of Contract for Plant and Design Build for Electrical and Mechanical Plant and for Building and Engineering Works designed by the Contractor ("the Yellow Book").

The parties agreed to specific amendments to Yellow Book clause 8.7, which provided for the deduction of delay damages from the next applicable payment cycle if Murphy failed to achieve various accreditation milestones and Taking-Over within prescribed periods.

In addition, the contract contained an unamended version of clause 2.5 of the FIDIC Yellow Book (which also appears in the Red Book). Clause 2.5 requires the Employer to give notice and particulars, as soon as practicable, to the Contractor and for the Engineer to proceed to agree or determine the amount, if any, which is due from the Contractor, before the Employer is entitled to set-off, make any deduction or otherwise claim against the Contractor.

Following significant delays in the progress and completion of the Works, disputes arose as to the responsibility for such delays, with Beckton seeking to deduct delay damages and Murphy seeking to obtain an extension of time and additional payment.

During the course of correspondence Beckton intimated to Murphy that it considered it was entitled to delay damages of circa £8 million. As such, Beckton gave notice of its intention to make a demand under the performance bond that was being maintained in accordance with an amended version of clause 4.2 of the Yellow Book. This clause was substantially different to the equivalent Yellow Book provision, as the express link between the Employer's right to call on the bond and a clause 2.5 determination had been deleted.

In the circumstances, Murphy sought urgent declaratory relief in respect of the following issues:

  1. Whether the Employer's ability to deduct delay damages was subject to compliance with the procedure under clause 2.5? and
  2. If so, whether a call on the performance bond could be restrained on the ground that it was fraudulent?

Decision

Issue 1: whether the Employer's ability to deduct delay damages was subject to an Engineer's determination in accordance with clause 2.5?

In determining this issue, the Court was required to address the apparent conflict between clauses 2.5 and 8.7.

In doing so, it set out the general principles that were relevant to identifying the parties' intentions which included, among other things, the natural and ordinary meaning of the clause, any other relevant provisions, the overall purpose of the clause and the contract, the factual matrix and commercial common sense.

As part of this assessment, the Court noted that, on the one hand, clause 2.5 was in the 'widest terms' and provided a clear procedure which applied if the Employer considered itself entitled to any payment under the contract or otherwise. The Court highlighted the remarks of Lord Neuberger in the recent Privy Council judgment of NH International (Caribbean) Ltd -v- National Insurance Property Development Company Ltd [2015] UKPC 37 in which he emphasised that "where the Employer fails to raise a claim as required..., the back door of set-off or cross claims is firmly shut".

However, against that backdrop, the Court had regard to the following:

  1. Clause 8.7 provided a self contained regime for the entitlement to make deductions in respect of delay damages and included an unqualified right to pay.
  2. The standard version of Clause 8.7 had been amended by deleting the qualifying words "subject to clause 2.5", which, objectively assessed, was consistent with the parties' intention that clause 2.5 would not apply in relation to the operation of clause 8.7.
  3. The inconsistencies between clauses 2.5 and 8.7 could be resolved by construing clause 8.7 as providing an independent regime in respect of delay damages, while clause 2.5 would continue to have effect in relation to the Employer's claims under, for example, clauses 7.6 [Remedial Work], 8.6 [Rate of Progress], 11.4 [Failure to Remedy Defects] and 15.4 [Payment after Termination by Employer] of the Yellow Book.

On balance, and in seeking to give effect to both clauses, the Court concluded that, on a proper construction the right to deduct delay damages was not subject to the clause 2.5 claims mechanism.

Issue 2: fraudulent demand?

Notwithstanding the findings in relation to the validity of the proposed deduction of delay damages, the Court proceeded to consider whether a demand which was founded upon a failure to comply with clause 2.5 would engage the fraud exception to the on-demand nature of performance bonds i.e. on the basis that there could not have been an honest belief in the validity of the demand.

The Court addressed this issue in short order, noting that the Employer's failure to obtain a clause 2.5 determination would not mean that the Contractor had no liability to account for delay damages, and that such failure did not cut across the Employer's entitlements that had accrued under clause 8.7.

Rather, it was the Employer's belief in its entitlement which triggered the performance bond and it was permissible for the Employer to assert its claim under the bond in good faith.

The Court also noted that it was in the nature of a performance bond that there would need to be a form of accounting in the light of a subsequent determination of the parties rights and as such it was not relevant that the sum demanded may differ from an amount which is finally determined.

In the circumstances, it was not possible to restrain the call on the performance bond.

Comment

While this judgment reinforces the Privy Council's judgment in NH International, which was seen to provide a fair balance between the competing interests of an Employer and Contractor, it provides a useful illustration as to how contracting parties may circumvent the effect of the default wording of clause 2.5 of the FIDIC suite and thus to enable an Employer to make deductions without requiring an Engineer's determination.

Of wider interest to practitioners is the Court's approach to interpreting deleted words from a standard form contract in ascertaining the parties' intentions. Further, particularly in light of the effect of the amendments to clause 4.2, this case serves as a stark reminder of the risks associated with amending a standard form without an appreciation of the implications on the contract as a whole.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.