UK: Negligence, Letters of Intent and contract administration

Last Updated: 21 August 2006
Article by Victoria Pecket and Billie Bingham

How many times do disputes arise on construction projects because the parties involved have rushed into commencing works on site without sufficiently advancing the design, or considering which form of contract to use, or agreeing contract terms? All too often parties will simply rely on Letters of Intent which (given the number of points outstanding) are vague and give the parties little assistance in determining how to proceed in the event things don’t go according to plan. Nonetheless commercial imperatives are such that parties will often need to get on with the works without all the contractual Is being dotted and Ts crossed.

A recent judgment from the Technology and Construction Court (Cunningham and others v Collett and Farmer [2006] EWHC 1771) has provided some useful guidance as to when it may be appropriate to use Letters of Intent and how Contract Administrators should act in issuing and accepting tenders and recommending the most appropriate standard form of contract for the project in question.

To view the article in full, please see below:


Full Article

How many times do disputes arise on construction projects because the parties involved have rushed into commencing works on site without sufficiently advancing the design, or considering which form of contract to use, or agreeing contract terms? All too often parties will simply rely on Letters of Intent which (given the number of points outstanding) are vague and give the parties little assistance in determining how to proceed in the event things don’t go according to plan. Nonetheless commercial imperatives are such that parties will often need to get on with the works without all the contractual Is being dotted and Ts crossed.

A recent judgment from the Technology and Construction Court (Cunningham and others v Collett and Farmer [2006] EWHC 1771) has provided some useful guidance as to when it may be appropriate to use Letters of Intent and how Contract Administrators should act in issuing and accepting tenders and recommending the most appropriate standard form of contract for the project in question.

One of the main lessons from the judgment is that Letters of Intent can be appropriate, but parties should be realistic and careful in their usage. To minimise risk, if you are using a Letter of Intent you should incorporate limits to the amount of work to be done by reference to a maximum monetary value that should not be exceeded by the contractor; and / or minimal work packages of works to be commenced under the Letter.

In the case before the TCC, the claimants had engaged the defendants to act as their Architect/Contract Administrator for the proposed refurbishment of a listed building. After some work had been carried out the defendants ceased work and claimed payment of their outstanding fees. The claimants brought claims against the defendants which included numerous allegations of negligence. The judge decided that the claimants had failed to establish negligence and commented on the key allegations made by the claimants as follows:

Allegation: "The Architect had been negligent in recommending the use of the JCT Minor Works Form".

There was nothing intrinsically wrong with the choice of JCT MW and indeed it had certain advantages over other JCT forms. The fact that the likely contract sum would be significantly higher than £100,000 (the recommended maximum for contracts let on JCT MW) was irrelevant.

The choice of which standard form of building contract should be used for a particular project will usually come down to the consultant’s personal preference and his previous experience. Such a subjective basis for choice is entirely reasonable. If a person likes and understands the way a particular standard form works then, unless there is a very good reason why it should not be used in a particular instance, it would be to everyone’s advantage if that form is recommended for use on projects.

The judge also commented that when a bespoke schedule of amendments is proposed for use with a standard form of contract it is best for it to be issued at the same time as the tender. At the latest they should be issued at the same time as the Letter of Intent. (In this case the schedule was issued later, but was accepted by the contractor without demur, and therefore nothing turned on the delay in issuing it.)

Allegation: "The Architect had been negligent in appointing the Contractor when there were insufficient tenders".

The Judge rejected the allegation that there were insufficient tenders to allow a properly competitive price to be identified for the project. The Architect had acted quite properly, in the circumstances, seeking five tenders and ending up with three.

Allegation: "The Architect had been negligent in appointing the Contractor when the design had been insufficiently developed".

The allegation proceeded from the fact that within the Contractor’s tender there was approximately £260,000 worth of provisional sums (within a tender sum of approximately £605,000). The Judge held that it was impossible to conclude that the mere fact that there was a large element of provisional sums within the Contractor’s tender somehow demonstrated a negligently incomplete design. It was rare for any refurbishment project to go out to tender with every last element of the works designed, particularly on a refurbishment project when the precise condition of the existing property would not be known prior to opening up.

Allegation: "The Architect had been negligent in recommending that a letter of intent should be entered into when such was inappropriate as a matter of principle and inappropriate in the light of the matters that remained to be agreed".

Letters of Intent are sometimes the best way to get works started on site without waiting for a formal contract to be settled. However they often leave parties exposed to uncertainty that the contract may never get signed. The judgment provides useful guidelines for when a letter of intent would be appropriate:

  • the workscope and price are agreed (or a clear mechanism is in place to agree them)
  • the terms of main contract documents are agreed or very likely to be agreed
  • the programme dates are broadly agreed
  • there are good reasons to start works in advance of completing main contract documents.

The Judge warned that Letters of Intent should not be used where to do so would be premature, or where the parties are simply hoping difficult contract issues will somehow disappear. He also emphasised that if a Letter of Intent is used then there will inevitably be some risk to both parties, no matter how carefully it is drafted. The purpose of a carefully drafted Letter of Intent is, however, to minimise such risks.

Allegation: "The Architect had been negligent in failing to get the principal contract agreed".

It was found that the main cause of the delay in getting the contract agreed was the Employer’s failure to agree the wording of the escrow agreement. The Architect could not be criticised for agreement of the contract terms or the administration of the letter of intent.

This article was written for Law-Now, CMS Cameron McKenna's free online information service. To register for Law-Now, please go to www.law-now.com/law-now/mondaq

Law-Now information is for general purposes and guidance only. The information and opinions expressed in all Law-Now articles are not necessarily comprehensive and do not purport to give professional or legal advice. All Law-Now information relates to circumstances prevailing at the date of its original publication and may not have been updated to reflect subsequent developments.

The original publication date for this article was 17/08/2006.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.