UK: What "Delay" Counts Towards Cancellation?

Last Updated: 6 February 2015
Article by Deug Rong Lee and Thomas Kelly

With tumbling oil prices and projects being mothballed or cancelled, knock-on effects are to be expected. Offshore contractors with vessels or rigs under construction in yards are less likely to be tolerant of construction delays than they would otherwise be, and may consider cancellation. The recent Commercial Court decision in Zhoushan Jinhaiwan Shipyard Co Ltd v Golden Exquisite Inc & Others [2014] EWHC 4050 provides a timely look at cancellation rights in the context of delay.

Facts

In Zhoushan, the buyer had purported to exercise its right to cancel under a series of materially identical shipbuilding contracts, on account of periods of accumulated delay in delivery. Article VIII.3 of the contract permitted the buyer to cancel if the total accumulated delay exceeded a certain number of days, but certain categories of delay could not be included in the calculation. One of the excluded categories was for delays "....due to default in performance by the buyer". The court recognised that, in each case, the cancellation of the contract by the buyer followed a similar pattern:

  • The delivery of the vessel was delayed beyond the "delivery date" (as defined in Article VII of the contract)
  • The buyer gave notice of cancellation of the contract on a date which was more than 270 days after the delivery date (being the relevant period of accumulated delay giving rise to a right to cancel under Article III of the contract)
  • Before such notice of cancellation was given, the yard had not given notice to the buyer of any delay which the yard claimed had been caused by a breach of contract by the buyer (or any other cause for which the yard was not responsible)
  • After notice of cancellation had been given, however, the yard did make such a claim and alleged that breaches of contract by the buyer had resulted in delays in the construction of the vessel totalling, variously, not less than 90 days or 100 days depending on the case

The yard argued that the cancellation was wrongful because part of the delay was, on its case, caused by the buyer's own breach of the contract, namely that during construction, the buyer had breached its obligations relating to the inspection of the ship by the buyer's supervisor (under Article IV). Essentially, the yard complained that the supervisor worked too slowly and sought to impose unreasonable requirements on the build.

If the cancellations were lawful, the buyer would be entitled, under Article X, to a refund of all instalments of the contract price which had been paid before the cancellation, together (potentially) with interest on those instalments, from the date of payment to the date of repayment. If the cancellations were unlawful, the yard would be entitled to keep the instalments and re-sell the vessels, crediting the buyer only with the balance of the proceeds of any such sale, after the yard has recouped its expenses.

Decision

The court (Leggatt J) held, on an appeal from previous arbitral awards, that the exception under Article VIII.3 for delays "due to default in performance by the buyer" had to be understood, in context and as a matter of contractual interpretation, as a reference only to those types of default by the buyer in respect of which the contract expressly provided for an extension of the delivery date. (An example of a specific provision to this effect was Article XI of the contract, which covered (amongst other things) failure by the buyer to make payments on time, and had the effect of postponing the delivery date so long as that default continued).

The court considered that the overall contractual scheme indicated that breaches of the kind of which the yard complained were not ones which were intended to entitle the yard to make late delivery, whatever other remedies the yard might have. In coming to this view, the court observed that for other breaches by the buyer, the contract provided for a formal extension of the delivery date, and required notice by the yard of its intention to rely upon such breaches to extend this date, but this was not so in relation to breach of Article IV.

The court concluded that the parties were unlikely to have intended for the yard to be able to rely on a period of delay without it having to give notice of this to the buyer, and observed that this interpretation would avoid an undesirable situation in which the parties might be unsure, at any given point, whether the contract could or could not properly be cancelled. The yard's interpretation, if accepted, would cut across this scheme. As the judge put it:

"The parties could no doubt have made a contract which left them each to perform their own calculation and then argue about the causes of delay after a cancellation has occurred. However, they have tried to avoid such an anarchic situation. Instead, they have adopted a scheme which provides for notices to be given and agreement reached, or any dispute resolved by arbitration if necessary, whenever an event occurs which the Yard wishes to say justifies an extension of the time for delivery."

It followed that the shipyard's arguments had failed, and the court upheld the findings under the arbitration awards to the effect that the buyer's cancellation of the contracts was justified, and the yard was obliged to repay the full amount of the instalments advanced by the buyer.

Comment

Although the decision turned on the particular wording of the contract in question, it may provide some guidance as to the interpretation of other shipbuilding contracts, particularly those, as appears to be the case here, based on the widely used SAJ (Shipbuilders' Association of Japan) form. Some key points to note are:

  • Standard provisions relating to termination and delay are frequently subject to extensive amendment by the parties. This decision highlights the potential significance of any ambiguity around which categories of delay do, and which do not, count towards the accumulated period permitting the buyer to cancel
  • The decision suggests that buyers should, perhaps, hesitate to take at face value assertions by a yard that particular periods of delay are to be disregarded for the purposes of establishing buyers' cancellation rights. It would seem that the court/ tribunal may be slow to accept such arguments unless the wording is clear, particularly if the result would be that the yard would not have to give any notice of its intention to rely on the relevant delay
  • In a similar vein, the case recognises the importance of contractual notice regimes where they appear. The court showed hostility to interpretations of the contract that would allow the yard to exclude periods of delay for the purposes of calculating buyer's cancellation rights without first giving notice of its intention, and only after the buyer had purported to terminate for excessive delay.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Thomas Kelly
 
In association with
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.