UK: They Protesteth Too Much: Construction Sites And Protesters

Last Updated: 2 July 2012
Article by Fritha Wheeler-Ozanne

The recent High Court litigation involving the Olympic Delivery Authority ("ODA") and protestors at Leyton Marsh sheds light on how the law assists owners and occupiers of construction sites against obstructive protesters.

The Facts

The ODA is the body responsible for the planning and delivery of the Olympic Games, 2012.  As part of its remit, the ODA is obliged to build a number of venues, including a basketball facility within an area known as Leyton Marsh.  The ODA was obliged to (and did) deliver this particular venue to the London Organising Committee of the Olympic and Paralympic Games ("LOCOG") by 7 June 2012.

The basketball facility is a temporary one and, as part of the planning permission for the venue, the ODA is obliged to remove the facility and reinstate the land by October 2012.  Notwithstanding this, there was considerable outrage from local residents (and others, including "Occupy London") who took to obstructing access to the site by a number of means (including playing games of boules on the access route to the site and gluing gates shut).  As a result, the ODA's works were disrupted at an estimated cost of £8,000 per day.  The ODA was also at risk of jeopardising the June handover to LOCOG, which would have had severe financial and reputational consequences for both. 

In the circumstances, the ODA made an application for an injunction to prevent the protestors from obstructing access to and from the site.  Their claim was principally based on the tort of private nuisance.  Private nuisance is an unlawful interference with the rights of an owner or occupier of land caused by an action (or inaction) on a neighbour's land.  The tort is often considered in the context of construction, where demolition and re-building are likely to result in some level of inconvenience for neighbours.  However, the interference must be substantial and unreasonable for the tort to come into play.  Where the inconvenience is temporary and, where reasonable steps have been taken to mitigate it, the courts are generally unlikely to find that the owner or occupier's rights have been infringed. 

In this case, the ODA had been granted an exclusive licence to use the site for the purpose of building the temporary basketball venue.  The licence agreement also provided for access to and from public roads to the site.  As such, the ODA claimed that it had sufficient interest in the land by virtue of the licence agreement to make the application and the protestors' actions, in deliberately preventing access, constituted an actionable wrong. 

The Court's Decision

The judge agreed, subject to the questions of whether the protestors' rights to freedom of expression and freedom of assembly under the European Convention of Human Rights had been engaged and, if so, whether they should be restricted.

The judge found that both rights had been engaged by virtue of the overwhelming evidence of the protestors seeking to express their views on the development within Leyton Marsh.  In assessing whether those rights should be restricted, the Judge considered the proportionality of the order sought and, in particular, recent guidance from The Mayor Commonalty and Citizens of London v Samede (2012) relating to the protest at St Paul's Churchyard.  In that case, the Court recognised that such decisions would be largely dependent on the individual facts of a case, including "the extent to which the continuation of the protest would breach domestic law, the importance of the precise location to the protesters, the duration of the protest, the degree to which the protestors occupy the land, and the extent of the actual interference the protest causes to the rights of others, including the property rights of the owners of the lands, and the rights of any member of the public." 

The judge held that the order sought by the ODA was wholly proportionate since it did not seek to evict the protestors or prevent them from continuing with their camp or displaying their banners, but simply to prevent the unlawful obstruction of access to the site. 

The injunction was, however, only effective for two weeks. At the expiry of that period, the ODA made a further application for the continuation of the injunction on the basis that the situation was, if anything, worse.  Deliveries had been obstructed by protestors lying in front of and under vehicles, contractors continued to be subjected to abuse and several arrests had been made.  The ODA was therefore increasingly concerned about meeting the handover deadlines, and their escalating costs.   The judge held that the protestors' environmental concerns were legitimate matters of concern, but saw no reason why the protests could not continue without obstructing the ODA's access.  In the circumstances, the injunction was continued until a trial could be heard or, if earlier, October 2012 when the licence expires and the ODA is obliged to reinstate the land.

Commercial Implications

The ODA stressed the potential financial losses it would suffer because of the delay caused by the protestors.  The question of who bears the risk for any delay and / or disruption caused by protestors will very much depend on the terms of the parties' contract regarding force majeure events. 

Under the JCT standard form of contract, civil commotion is listed as a relevant event, entitling a contractor to an extension of time, but not any compensation.  FIDIC lists a riot, commotion or disorder as an example of an event that will excuse a party from performance of their obligations, so long as the event is (broadly speaking) exceptional and the relevant notice has been issued.  In certain circumstances, a contractor will not only be entitled to an extension of time, but also costs.  For the force majeure provisions to come into play under an NEC 3 form of contract, a protest would require to be (i) unpreventable and (ii) so unlikely to occur that a reasonable contractor would not have allowed for it.  If the protest then either prevents completion or prevents completion on time, the project manager will be entitled to issue instructions and the contractor will be entitled to compensation for the associated time and cost of dealing with the instruction. 

It is worth bearing in mind that force majeure provisions are sometimes interpreted narrowly and are often accompanied by strict notice provisions.  

Conclusion

The case offers useful guidance on a contractor's rights where access to a construction site has been blocked by protestors.  However, it is worth noting that had the protestors occupied the site, rather than just the access route and adjacent land, the ODA would have been able to exercise additional rights, including an order for possession against trespassers (as discussed in Manchester Airport Plc v Dutton, 1999), and the ODA (or its agents) would have been entitled to exercise reasonable force to evict the protesters.

References:  Olympic Delivery Authority v Persons Unknown [2012] EWHC 1012 (Ch) and  Olympic Delivery Authority v Persons Unknown [2012] EWHC 1114 (Ch)

This article was written for Law-Now, CMS Cameron McKenna's free online information service. To register for Law-Now, please go to www.law-now.com/law-now/mondaq

Law-Now information is for general purposes and guidance only. The information and opinions expressed in all Law-Now articles are not necessarily comprehensive and do not purport to give professional or legal advice. All Law-Now information relates to circumstances prevailing at the date of its original publication and may not have been updated to reflect subsequent developments.

The original publication date for this article was 25/06/2012.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.