UK: Proceeding Regularly And Diligently And The "Hurry-Up" Notice

Last Updated: 18 January 2012
Article by Dr. Stacy Sinclair

The recent case of Leander Construction Ltd v Mulalley & Co Ltd [2011] EWHC 3449 (TCC), helps to clarify the law in relation to implied terms requiring a party to proceed regularly and diligently.

The Facts:

In September 2010, Mulalley (the main contractor) engaged Leander (the sub-contractor) to carry out groundworks, drainage, the concrete framework and other associated works at a development known as Tigers Head in Lewisham. By May 2011 it was clear that the sub-contract works were delayed - each party blamed the other. Mulalley served two withholding notices as a result of the alleged delays, claiming that Leander had failed to carry out the sub-contract works in accordance with the programme dates and period set out in the Activity Schedule. Ultimately, Leander commenced proceedings in the Technology and Construction Court.

Mulalley argued that, although the sub-contract did not expressly state so, Leander had an implied obligation to proceed regularly and diligently with the works. It alleged that this implied term must be incorporated into the sub-contract in order to give the sub-contract business efficacy – or in other words, both parties must have intended this term to be part of the contract, as the contract simply would not work without it from a commercial perspective. Leander argued that there was no such implied term.

The Issue:

Did Leander have an implied obligation to proceed regularly and diligently?

The Decision:

Mr Justice Coulson reviewed the relevant test for implying a term into a contract (BP Refinery (Westernport) Pty Limited v shire of Hastings) and held that Mulalley had failed to show that the implied term to proceed regularly and diligently was necessary to give the sub-contract business efficacy. Even though this term had not been included, the sub-contract was adequate and still provided the parties with the sufficient information to evidence the deal that had been agreed. In addition, all previous authorities pointed the same way: 'the courts are very reluctant to imply additional terms as to the timing or regularity of the contractor's performance prior to the contract completion date', particularly where there was already a contractual completion date established in the contract - as there was here.

Commentary:

Mr Justice Coulson's reference back to the 1994 case of West Faulkner Associates v London Borough of Newham will be of interest to contract administrators. In that case, West Faulkner, a firm of architects, was found to be in breach of their contract administration duties when it failed to give the contractor a notice that he was failing to proceed regularly and diligently with the work. It was an express term of the JCT63 contract that, provided the contractor was served with the requisite notice under clause 25(1), the employer (Newham) was entitled to terminate the contract if the contractor failed to proceed regularly and diligently. West Faulkner failed to serve the notice. The employer sued the architect. Though the architect argued that the meaning of the clause and indeed the term 'regularly and diligently' was obscure, the Court of Appeal held that in this situation no reasonably competent architect could have arrived at the conclusion it did.

When acting as the contract administrator, it is therefore important to fully understand the contractor's obligations. In the West Faulkner case, the Court of Appeal held that the term 'regularly and diligently' meant:

"Taken together the obligation upon the contractor is essentially to proceed continuously, industriously and efficiently with appropriate physical resources so as to progress the works steadily towards completion substantially in accordance with the contract requirements as to time, sequence and quality of work. Beyond that I think it impossible to give useful guidance. These are after all plain English words and in reality the failure of which clause 25(1)(b) speaks, is, like the elephant, far easier to recognise than to describe."

Accordingly, as a similar provision is included in the JCT 2011 Standard Building Contract, contract administrators must therefore recognise when to issue this 'hurry-up notice' – a term coined by Mr Justice Coulson – or alternatively, seek legal advice.

This article is one of a series contributed by Fenwick Elliott to the Building website. To see further articles in this series please go to www.fenwickelliott.com/legal-briefing.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Dr. Stacy Sinclair
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions