UK: Liquidated Damages And Termination

Last Updated: 15 August 2010
Article by Christopher Hill, Steve Abraham and Donald Warnock

In the following case the court had to consider whether an employer's right to liquidated and ascertained damages ended upon termination of the employment of the contractor under the contract.

Hall & Shivers v Van der Heiden No 2 [2010] EWHC 586 (TCC)

The employer entered into a JCT Minor Works Building Contract (With Contractor's Design) for "internal refurbishment and remodelling" of a domestic flat in London. The contract commencement date was 21 May 2007 and completion was scheduled for 22 September 2007. Liquidated damages for delay were specified as £700 per week.

The scheduled date for completion was not achieved and disputes arose between the parties which included the claim by the employer for liquidated damages for delay in completion of the works.

In January 2008 the contractor requested an extension of time, further payment and suspended the works. The architect awarded a six week extension of time to November 2007 but did not issue any further certificates for payment. The employer had paid all the sums which had been certified by the architect. (The employer had in fact been making interim payments in advance of the contractor's applications for payment the effect of which was that until December 2007 the payments to the contractor were in fact higher than the sums to which the contractor was entitled.)

In March 2008 the employer terminated the contractor's employment under the contract. The works were eventually completed by a replacement contractor in May 2008.

Practical completion: the principles

One of the issues before the court was the date of practical completion, and whether or not the contractor ever achieved practical completion of his works before suspending them in January 2008.

The court considered the principles for determining whether practical completion had been achieved:

  • Practical completion meant the completion of all the construction work that had to be done (Jarvis and Sons v Westminster Corp [1970] I WLR 637).
  • An architect had a discretion to certify practical completion where there were very minor items of work left incomplete on 'de minimis' principles: (HW Nevill (Sunblest) v William Press (1981) 20 BLR 78).
  • A practical completion certificate could be issued where there were latent defects but not where there were patent defects.

Practical completion: applying the principles

The court's view was that there was no doubt that the works were not practically complete in January 2008 because there were:

  • a series of patent defects which were the subject of repeated written notices and complaints from the architect and from the employer during December 2007 and January 2008 which the contractor failed to rectify;
  • a number of incomplete items which the contractor had failed to complete; and
  • several completed items off-site which had not been bought back to site.

In the court's view practical completion of the works was only achieved once the replacement contractor had completed the outstanding works in May 2008. Consequently the contractor was in delay from November 2007 and that delay extended beyond the period of suspension to May 2008, a delay of 29 weeks (the Period of Delay).

Liquidated damages and termination

The employer sought liquidated damages for the Period of Delay. However, the contractor argued that its liability to pay liquidated damages ceased when the contractor's employment under the contract was terminated in March 2008 and not when the works achieved practical completion.

Mr Justice Coulson rejected the contractor's argument "as a matter of principle" leaving the employer able to claim liquidated damages beyond termination of the employment of the contractor under the contract on the basis that:

(i) there was no provision in the contract to the effect that the liquidated damages ceased to be payable in such circumstances. In his view "any such term would reward [the contractor] for his own default"; and

(ii) a contractor who was in considerable delay and facing a notice of termination should not be liable for liquidated damages only until termination as this would reward the contractor for "sitting on his hands and failing to carry out the works ..." - that could not be a commonsense interpretation of the contract or indeed any other construction contract.

As a result the employer succeeded in its claim for liquidated damages beyond termination of the contractor's employment under the contract.

Editors' comments

The case concerned a JCT Minor Works contract which in common with other JCT standard forms contains a provision that one of the consequences on termination is that "any further payment or any release of Retention to the contractor" will cease. This provision suggests that the payments which cease would be those made by the employer to the contractor rather than payments made to the employer (such as liquidated damages). However, it should be noted that the contractor did not appear at trial and gave no evidence so no counter-argument was made to the court.

The termination provisions in the JCT standard form contracts also provide for the termination of the "employment of the contractor" rather than the termination of the contract itself. If the employment of the contractor is terminated (rather than the contract itself), the argument is that the contract and in particular any clauses providing for the consequences of termination, such as clauses providing for the continued use of plant and materials or assignment of contracts, remain alive.

However, Hudson in Building and Engineering Contracts (11 edition), a leading construction text, suggests that the distinction between terminating the contract and terminating the employment of the contractor is simply "poor and diffuse draftsmanship" (para 12-008), which stems from the fact that it took some time for it to be established in common law that contract repudiation still required certain contractual provisions, such as the dispute resolution clause, to survive the termination (Heyman v Darwins Ltd [1942] AC 356).

Hudson also suggests that unless the contract contains an express provision to the contrary, the position regarding liquidated damages and termination is as follows:

  • the employer is entitled to liquidated damages for delay up to the date of termination;
  • after the date of termination the employer's entitlement is to recover any additional damages for delay and the additional completion costs by way of general damages.

This is in line with the thinking that a contractor has no ability to affect the completion date after termination has taken place so it would not be appropriate to apply a liquidated damages clause to completion by a subsequent contractor (without express wording to this effect). Indeed the subsequent contractor could further delay the works.

The practical solution would be for contract drafters to include express provisions making it clear what would happen to the liquidated damages provisions in the event of termination.

View: Hall & Shivers v Van der Heiden [2010] EWHC 586 (TCC)

This article was first published in the Norton Rose Construction and infrastructure updater June 2010

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions