Turkey: How To Secure Projects: The Significance Of Insurance In Project Finance

Extended liquidated damages insurance

In the last 5 or 6 years some projects have had the benefit of insurance which is designed to pick up the risk after the contractor's liability has been exhausted, these kind of policies mirror the construction contract provisions in relation to time and put the insurer on risk after the date for mechanical completion (as extended pursuant to the EPC contract) and contain an excess which is usually equal to the extent of the liquidated damages which the contractor has agreed to pay for delay. Additionally these policies are relatively unusual and bespoke as well. The insurers will engage in an exercise of due diligence. They will be particularly interested to understand the quality of the contractor and its previous performance. Therefore, insurance is more likely to be obtained if the contractor is an international organization of repute and they will be particularly interested to understand the extent to which the contractor has accepted liability for the losses due to the delay in relation to the design. Any bankability studies by independent engineers are of assistance, but the insurers will usually engage engineers to do a further review; moreover they will be keen to establish that there is no novel or experimental engineering associated with the project. They will seek disclosure in proposal forms relating to this issue. They will also seek to make it a warranty to the effect that the project does not contain any such novel or experimental technology.

Commissioning and ramp up

Each process plant is unique. Accordingly, it is always anticipated that it will take some time from mechanical completion to commission the plant and ramp it up to full production.

At this stage of the project, the owner invariably wants to be in control of the plant. However, particularly with inexperienced owners, there is significant risk that it will not have the technical or other expertise to effectively ramp up the plant to full production or educate its operators as to how to operate the plant.
For these reasons, where, firstly there are inexperienced owners; or
 the project is financed on a limited recourse basis.

The owners will sometimes enter into an agreement whereby the EPC contractor or perhaps the process provider, provides commissioning and ramp up assistance.

Such contracts often stipulate a ramp up curve and liquidated damages for failure to achieve production levels anticipated at the time of contract.

Usually, the liquidated damages stipulated are a cap on the contractor's liability. The prevention principle is very important. If the production levels set are not achieved as a consequence of an act or omission of the owner then, pursuant to the prevention principle, it is highly arguable that the liquidated damages payable pursuant to such a ramp up agreement will be unenforceable. When coupled with an exclusion of all consequential loss liability the owner will arguably be left with no remedy.
This outcome is a distinct possibility in circumstances where the owner has taken over responsibility for the operation of the plant. Accordingly it is recommended that there be a mechanism, similar to an extension of time provision under a conventional construction contract, whereby the thresholds stipulated in the contract can either be adjusted or the period in which performance is to be achieved can be changed to take account of acts or omissions of the owner.
Again, it is also important to ensure that the liquidated damages clause is not a penalty and is a genuine pre-estimate of the loss.

Works insurance

Works insurance or Construction All Risk (CAR) insurance is a fundamental component of risk mitigation in process engineering projects for both the owner and the EPC contractor. However it should be noted that this type of insurance has significant limitations. In addition there is a marked difference between the risk that is covered by policies that cover projects occurring offshore and those occurring on-shore.

The primary purpose of CAR insurance is to insure the physical works or facilities being constructed against loss or damage arising from an "occurrence". In other words this type of insurance is an event-based insurance where the insurance will trigger if an "occurrence" happens which causes physical loss or damage to the works. "Occurrence" will be defined by the policy wording but in general it will include events such as fire, natural disaster as well as the negligence of or mistake made by one of the parties. Both the owner and the EPC contractor are named as insured and it is common for either the owner or the EPC contractor to take out the insurance.
With such policies care should be taken, where a party to the construction contract give indemnities to the other party which are also given by an insurer, to:avoid creating coordinate liabilities between the indemnifying party and the insurer which would give the insurer the right to seek contribution from the indemnifying party;ensure that the policy of insurance taken out in the joint names of the parties has a waiver of subrogation clause, to avoid the insurer subrogating to the non-indemnifying party's right and seeking to recover from the indemnifying party

Finally, exclusions of liability can become problematic. The extent and nature of the exclusions will have a significant impact on the risk allocation that will be agreed as between contractor and owner. In this regard there is a major difference between the likely approach for an on-shore project and an offshore project given that the nature of exclusions in offshore CAR policies has undergone significant recent change.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
Related Articles
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions