Canada: The Superior Court Confirms The Criteria Related To The Termination For Cause Of A Subcontracting Agreement And Resulting Damages

Litigation and Dispute Resolution Bulletin
Last Updated: May 14 2019
Article by Annie Bernard, Christine Provencher and Jean-François Trudelle

Upon examining if there were sufficient grounds to terminate the subcontracting agreement between Litostroj Hydro Inc. ("Litostroj") and Ideal Electric Company ("Ideal") for the production of generators in the context of Hydro-Québec's project to build two hydroelectric plants, the Superior Court (the "Court"), presided by Honorable Chantal Tremblay, SCJ, dismissed Ideal's claim in its entirety in the case I.E. Liquidation Inc. v. Litostroj Hydro Inc. In addition, the Court confirmed that the governing principles in the matters of: termination for cause, abuse of right in the execution and termination of contracts, the evaluation of the value of work in such a context, and lawful notification.

The Facts

In February 2005, Hydro-Québec retained the services of Litostroj as a supplier and installer of generating units for its project involving the construction of two hydroelectric plants in Haute-Mauricie. In July 2005, Litostroj executed two identical subcontracting contracts with Ideal for the design, production, installation, and activation of the generators (the "Contract").

The Contract contained a termination for cause clause in the event of insolvency, non‑performance, and work interruption or slowdowns by the subcontractor. Notwithstanding, and except in the event of insolvency, this clause required a written notice be sent to the subcontractor in which, prior to the termination of the Contract, the contractor must identify the alleged shortcomings and grant the subcontractor time to implement appropriate remedies.

From the beginning of the execution of the Contract, Litostroj observed certain problems related to the performance of the work by carried out by Ideal, specifically, as it pertained to the quality of the generators' production design. The financial viability of Ideal, who was unable to provide the performance bond provided for in the Contract, also concerned Litostroj.

As the months passed, Ideal accumulated delays and failed to perform its obligations. In the spring of 2006, Hydro-Québec noticed that the generators being designed and produced by Ideal contained design flaws and requested that Litostroj and Ideal correct the problem before undertaking the production of the components in question.

While offering assurances that the generators met the Hydro-Québec's contractual requirements, Ideal was slow to respond to Hydro-Québecs and Litostroj's concerns and did not implement all the necessary measures to remedy the design problems raised.

At the same time, Ideal, who claimed to be making strides in the production of the generators in question, demanded certain payment installments despite failing to meet all of its expected contractual requirements and obligations. In May and June 2006, to alleviate its subcontractor's financial burden and avoid even longer generator production delays, Litostroj acceded to Ideal's request for payment of agreed-upon amounts (minus deductions provided for in the contract) for the design of the generators. However, Litostroj withheld, during the summer of 2006, certain payments owed for the production of the generators until the design problems related to the coolers and the insulation of the upper levels of the generators were addressed.

In the weeks that followed, Ideal's shortfalls and delays progressively worsened. Ideal's financial difficulties also deepened such that, in August 2006, it requested that Litostroj modify the agreed-upon payment terms so that Ideal might better fund the project. At the time, to escape the impasse in which it found itself, Ideal also enlisted restructuring consultants.

Litostroj refused to modify the agreed-upon payment terms; however, it offered to purchase Ideal's assets, an offer Ideal refused. Several days later, Ideal sent a stop-work notification to Litostroj, citing Litostroj's withholding of payments.

On October 9, 2006, having determined that Ideal was insolvent and unable to meet its contractual obligations, Litostroj sent Ideal a notice of default and termination of the Contract. On October 27, 2006, Ideal accepted the termination of the Contract and, several days later, sought protection under U.S. bankruptcy and insolvency law.

In 2010, Ideal began judicial proceedings against Litostroj, alleging that it had caused Ideal's bankruptcy through its failure to pay during the performance of the Contract and the ostensibly abusive termination of the Contract. Ideal claimed compensation for damages in the amount of $10,660,931.18 (plus interest and additional compensation since the termination of the Contract), citing the alleged progress of Ideal's work at the time the Contract was terminated as well as damages suffered in the context of its bankruptcy.

Litostroj defended its termination of the Contract for cause and maintained that it owed no damages to Ideal. In a counterclaim, Litostroj also demanded reimbursement of the sums paid to Ideal for the design of the generators.

The Ruling

In a detailed judgment, the Court first concluded that, since it had enough information to surmise that its subcontractor was insolvent, Litostroj was within its rights to terminate the Contract for cause and to do so without notification. Furthermore, the Court confirmed that an expert opinion was not necessary to prove the insolvency of a party, when the insolvency was supported by facts, and that such a determination is to be left to the discretion of the court.

The Court then concluded that Ideal was also in breach of its contractual obligations and, despite the absence of the default notice provided for in the Contract, that it was lawfully notified given its repeated failings, the cessation of work in September 2006, and its acceptance of the termination of the Contract.

In short, the court concluded that Litostroj was justified in terminating the Contract and that it had not acted in bad faith or in an abusive way at the time of the termination.

In addition, the court refused to grant Ideal compensation for work performed and materials furnished when the Contract was terminated. Indeed, by applying the principlrs recognized by the Court of Appeal in Corporation Urgences-santé de la région de Montréal métropolitain v. Novacentre Technologie Ltée,[1] Judge Tremblay concluded that in the event of a termination for cause, when work performed or materials furnished are of no value to the co‑contractor, no compensation is owed because one cannot conclude that the services or materials were furnished.

Given Ideal's many shortcomings throughout the performance of its Contract, the court concluded that Litostroj did not behave in an abusive manner by withholding certain payments owed to its subcontractor and that Litostroj was under no obligation to modify the contractual payment terms to help Ideal address its financial difficulties. Thus, the court rejected in its entirety Ideal's claim.

Judge Tremblay also rejected Litostroj's counterclaim arguing that Litostroj had not established that the production designs were of no use to it, to Hydro-Québec, or to new subcontractors involved in the furnishing of generators.

Key Points

It its judgment, the Court confirmed the application of established principles regarding the business contract termination-penalty and defined the damages that can be claimed by a contractor (or a sub-contractor) in this context.

Furthermore, it highlighted the fact that a party's repeated failures to fulfill is obligations can constitute lawful notice and open the way for immediate termination without the necessity of a written notification. In addition, even if clear language exists providing that, in the event of termination, a contractor will be paid for work performed and materials furnished up to the moment the contract is terminated, a court can refuse to grant any damages if, due to a party's failings to perform work, the work and materials furnished cannot be exploited by the party's co-contractor.

Finally, the Court clearly established that, since a contract is essentially a self-serving act, good faith principles in the context of contractual relationships do not require that one party come to the aid of another or that it modify the agreed-upon terms of the contract, more specifically the financial terms of a contract.

A team at Fasken that included, among others, Annie Bernard, Christine Provencher and Jean-François Trudelle represented Litostroj in this case. As of the publication date of this bulletin, the judgment has not been appealed.


[1] 2014 QCCA 1594.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions