Canada: The Respective Responsibilities Of The Supplier And The Client In A Software Implementation Project

Last Updated: September 14 2018
Article by Jean-François De Rico and Pascal Archambault

What you need to know — Whether you are the supplier or the client, the scope and intensity of your obligations may vary depending on the type of project and the terms and conditions of the contract for the instalment and implementation of an information technology solution, such as a software suite or a migration to a cloud-based solution:

  1. If the supplier's role is specific and well-defined, its obligation may well be one of result, meaning that the supplier will not be excused for not fulfilling it unless it proves that its failure to do so was due to force majeure.
  2. If the mandate the supplier must perform is subject to vicissitudes or uncertainties (as is often the case), its obligation will only be one of means; that is, to act with prudence and diligence. The more the supplier's mandate is general in nature, the more its obligation will be subject to vicissitudes and likely to be considered by the courts as a mere obligation of means.
  3. If the project is to be carried out jointly, as is also often the case, the parties will be considered to share responsibilities, such that the client will also have obligations towards the supplier. In such situations, the parties are essentially each bound to deploy the necessary efforts and resources to ensure the project is carried out efficiently and effectively, to the extent commercially and reasonably possible.

It is thus important to bear in mind that projects for the implementation of IT solutions involve not only challenges that are specific to information technology, but also give rise to issues that may directly affect the client organization's activities and performance.

Attention must therefore be paid not only to the terms and conditions of use or the licence rights that govern the use of the solution, but also to the terms specifying the respective obligations of the supplier — whether it is designated as a consultant or integrator — and the client. It is thus important to take all of the foregoing into account when drafting a call for proposals and negotiating the applicable agreements, and to consult with a legal advisor.

Informatique Côté Coulombe Inc. v. Produits chimiques Magnus Ltée1  This case is an instructive example. In October 2006, the parties concluded various agreements, in particular one for the sale and installation of an integrated software suite, including updates, maintenance and technical assistance.

The client, the defendant in the proceedings, encountered difficulties with the software after the installation, and accused the supplier (the plaintiff) of having botched its installation and of not being able to fix the numerous problems the client was experiencing. The supplier, who had not been paid, sued the client, alleging that the problems were due to improper use of the software and/or a lack of training associated with poor internal management of the project by the client.

The Court allowed the supplier's action, based essentially on the following conclusions:

  • The parties agreed that they would act as a team in implementing the software. The client had an important role to play in the success of the implementation: while the supplier had the obligation to provide the software and know-how for the project, the client was obliged to deploy the necessary human resources.
  • The supplier had only an obligation of means, not of result. This was not a fixed-price or turnkey contract, and the unsuccessful implementation was not due to any failing or shortcoming on the part of the supplier. 

The Court's conclusions were based on the wording of the contract, the supplier's representations, and the correspondence between the parties. The evidence disclosed various material factors, including:

  • a bank of hours was established for the implementation, as well as a bank of hours for the customization of the software suite;
  • the importance of the role of the client's project manager and the availability of the employees in the departments involved;
  • the fact that the client was designated as the project lead, and the supplier's resources were to be used only for assistance in the software's deployment; and
  • the fact that the installation of the software required the client to agree to and make major changes in its activities, which necessitated devoting a significant amount of time to the implementation of the solution. 

Finally, the Court concluded that the various modules of the software solution were functional and that the failure of its implementation was attributable to deficient project management by the client. The Court noted in particular that the client failed to provide some key information regarding its business processes.

The Court therefore ordered the client to pay the supplier's invoices, notwithstanding the failure of the software implementation.

This article is not a legal opinion. Moreover, it essentially reproduces some of the expressions in the judgment referred to above in order to remain as faithful as possible to the Court's reasoning. For more information, we recommend that the reader refer to the judgment in question, which is available online.2


1 2018 QCCS 1494

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Jean-François De Rico
In association with
Related Topics
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions