Canada: Consolidated Contractors Group v Ambatovy: Ontario Court Of Appeal Reinforces Deference To Arbitration

In Consolidated Contractors Group v. Ambatovy,i the Court of Appeal for Ontario concluded that the arbitral award in an international construction case should not be set aside due to alleged defects in jurisdiction, procedural fairness, or for violation of public policy. The Court held that courts must defer to arbitral awards unless the applicant can meet the exacting standards to set aside an award contained in the Ontario International Commercial Arbitration Act, 2017.ii

Consolidated Contractors thus reinforces the principle of deference to international arbitral awards adopted by courts in Canada.

Background and Procedural History

CCC submits a dispute over construction delay to arbitration

The respondent, Ambatovy Minerals ("AM"), entered into a contract with the appellant, Consolidated Contractors Group ("CCG"), to construct a US$258 million slurry pipeline in a nickel mine in Madagascar. AM tendered the project and CCG was the contractor.

The contract contained a three stage dispute resolution clause. The first stage required disputes to be submitted to AM's supervising engineer. If that did not resolve the dispute, it would be referred to adjudication by a sole adjudicator. A party who did not accept the adjudication could refer the dispute to arbitration.

CCG claimed that AM breached the contract by causing delay and additional costs. In accordance with the contract, CCG initiated a claim with the respondent's supervising engineer but was dissatisfied with the engineer's decision. After CCG proposed to proceed to adjudication, the parties agreed to by-pass that second step and proceed directly to arbitration. The seat of the arbitration was Ontario and Ontario law applied. The ICC Rules governed the procedural aspects of the arbitration.

The arbitral tribunal awards a larger amount to AM

In the arbitration, AM asserted a series of counterclaims against CCG alleging, amongst other things, failure to complete the work on time. CCG agreed this issue could be arbitrated.

In its final award, the Arbitration Tribunal awarded only $7 million to CCG for its $91 million claim, and awarded $25 million to AM for its counterclaims.

Ontario Superior Court refuses to set aside the award

CCG brought an application in the Ontario Superior Court of Justiceiii to set aside the award on four alleged grounds:

  1. The Tribunal had no jurisdiction to deal with some of AM's counterclaims;
  2. The Tribunal failed to exercise its jurisdiction in not compensating CCG for costs due to delays caused by AM;
  3. The Tribunal denied CCG procedural fairness; and
  4. The award was partially in violation of Ontario public policy.

The Superior Court dismissed these attacks in their entirety and upheld the Tribunal's award. CCG appealed to the Ontario Court of Appeal, relying on the same grounds.

Ontario Court of Appeal Dismisses Appeal

The Court of Appeal applied section 34 of the 1985 UNCITRAL Model Law on International Commercial Arbitration with 2006 amendments (the "Model Law"). The Model Law is adopted by the Ontario International Commercial Arbitration Act, 2017.

Jurisdiction

Under Article 34(2)(a)(iii) of the Model Law, the court may set aside an arbitral award, or part thereof, where the tribunal acts outside the scope of its jurisdiction.

CCG raised two jurisdictional arguments. First, the appellant argued that the Tribunal wrongly assumed jurisdiction over certain of AM's counterclaims when they had not proceeded through the stages required by the dispute resolution clause in the contract. The Tribunal had found that the parties could not have intended for the dispute resolution steps to be conditions precedent to arbitration since the parties' intention in the contract was to resolve disputes efficiently. Since AM's counterclaim was intimately connected to CCG's claim, the Tribunal decided they should be decided at the same time, effectively dispensing with the procedure required in the dispute resolution clause.

The Court of Appeal held that the courts should not intervene on questions of jurisdiction except in rare circumstances:

The standard of review on questions related to a tribunal's jurisdiction under Article 34(2)(a)(iii) is one of correctness: Cargill, at para. 42. However, while endorsing a correctness standard in Cargill, Feldman J.A. was careful to limit the application of this standard to what she described as a "true question of jurisdiction", at para. 44:

It is important, however, to remember that the fact that the standard of review on jurisdictional questions is correctness does not give the courts a broad scope for intervention in the decisions of international arbitral tribunals. To the contrary, courts are expected to intervene only in rare circumstances where there is a true question of jurisdiction. [...]

This latter approach is magnified in the international arbitration context. Courts are warned to limit themselves in the strictest terms to intervene only rarely in decisions made by consensual, expert, international arbitration tribunals, including on issues of jurisdiction. In my view, the principle underlying the concept of a "powerful presumption" is that courts will intervene rarely because their intervention is limited to true jurisdictional errors...iv

The Court of Appeal held here there was no "true question of jurisdiction" since, as the Tribunal found, the parties' intention in the dispute resolution clause was to resolve disputes efficiently. The Court of Appeal agreed with the application judge's assessment that it was only a matter of time when the counterclaims would be arbitrated and not a matter of whether they were to be arbitrated at all:

The application judge rejected the appellant's submission that the Tribunal exceeded its jurisdiction in considering the counterclaims. In so doing, he noted that the appellant had full knowledge of the substance of those claims, had exercised a right to make a full and comprehensive defence to those claims and there was no evidence to suggest that the result would have been different had the claims gone through the pre-arbitration process.

[...]

The issue before the Tribunal was not a "true question of jurisdiction" in the sense used by Feldman J.A. in Cargill. The respondent's counterclaims were clearly the proper subject of arbitration under the contract. The only question, as noted by the application judge, was when they would be arbitrated. It was open to the Tribunal to find that the pre-arbitration dispute resolution process did not apply to claims of one party that were closely connected to the claims already submitted to arbitration by the other party.v

The Court of Appeal dismissed CCG's second argument that the Tribunal's failure to give specific reasons for awarding CCG "nil" for its delay claim was a jurisdictional error. Neither the Court of Appeal nor the application judge saw this as a "true question of jurisdiction", especially since it could be reasonably inferred that the Tribunal's reason for finding against CCG was that it had failed to prove its claim.

Procedural Fairness

Article 34(2)(a)(ii) of the Model Law permits a challenge to an arbitral award based on lack of procedural fairness if a party has not received proper notice of the proceedings "or was otherwise unable to present his case." CCG made arguments with respect to the latter.

The Court of Appeal applied a similarly high standard under this ground of the Model Law:

There are few cases in Canada addressing the standard of review under Article 34(2)(a)(ii). However, in Corporacion Transnacional de Inversiones S.A. de C.V. v. STET International S.p.A., Lax J. interpreted Article 34(2)(a)(ii) as including procedural as well as substantive fairness. She held, at p. 194, that to justify setting aside an award for reasons of fairness or natural justice, the conduct of the Tribunal "must be sufficiently serious to offend our most basic notions of morality and justice." Thus, she concluded, at p. 194, that "judicial intervention for alleged violations of the due process requirements of the Model Law will be warranted only when the Tribunal's conduct is so serious that it cannot be condoned under the law of the enforcing State." vi

CCG alleged it was denied procedural fairness on three grounds. First, CCG was not able to respond to AM's reply submissions, which were in breach of a Procedural Order prohibiting new arguments in reply. Second, CCG claimed that it was not given the opportunity to respond to a "novel theory" the Tribunal developed. And third, the Tribunal's allocation of costs violated procedural fairness because it was ultimately inconsistent with the parties' success on the merits. The Court of Appeal rejected these arguments, finding that none of CCG's complaints prevented it from presenting its case.

Public Policy

Under Article 34(2)(b)(ii) of the Model Law, the court may set aside an arbitral award if it conflicts with domestic public policy.

CCG alleged that a portion of the Tribunal's award was a penalty and therefore breached Ontario public policy. CCG argued that under the award AM recovered twice for CCG's delay, which was thus double recovery. The Court of Appeal agreed with the application judge and the Tribunal that the two payments performed different functions and were not capable of constituting double recovery even if they were both triggered by similar events or facts. The Court of Appeal held the "Tribunal's award does not come close to meeting the test" outlined in Schreter v. Gasmac Inc:

The concept of imposing our public policy on foreign awards is to guard against enforcement of an award which offends our local principles of justice and fairness in a fundamental way, and in a way which the parties could attribute to the fact that the award was made in another jurisdiction where the procedural or substantive rules diverge markedly from our own, or where there was ignorance or corruption on the part of the tribunal which could not be seen to be tolerated or condoned by our courts.vii

Conclusion

Consolidated Contractors reinforces the pro-arbitration attitude of Canadian courts, particularly in international arbitration. The courts will only set aside international arbitral awards in exceptional circumstances, and will not interfere in the Tribunal's award unless there was an error with respect to a "true question of jurisdiction". Moreover, a party seeking to set aside an award for breach of procedural fairness or Ontario public policy must meet the same high standard. Ontario courts will not permit the case to be re-argued before it.

Footnotes

i 2017 ONCA 939 [Consolidated Contractors].

ii S.O. 2017, c. 2, Sched. 5.

iii Reasons reported at 2016 ONSC 7171 (per Penny J.).

ivConsolidated Contractors, at para. 29.

v Consolidated Contractors, at paras. 40, 43, 52.

vi Consolidated Contractors, at paras. 40, 43, 52.

vii Cited with approval in Corporaction Transnacional de Inversiones S.A. de C.V. v. STET International S.p.A. (2000), 49 R.R. (3d) 414 (C.A.) at para. 2.

To view the original article please click here.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions