Canada: Case Summary: Vermilion & District Housing Foundation v Binder Construction Limited

Last Updated: February 26 2018
Article by Field LLP

Originally published October 2017


A. The Alberta Court of Queen's Bench holds surety liable under a performance bond for consequential damages suffered by an obligee as result of defaulting contractor.

Vermilion & District Housing Foundation v Binder Construction Limited, 2017 ABQB 365, per Nielsen, J. [4242]


In 2004, Binder Construction Limited ("Binder"), as general contractor, entered into a construction contract (the "Bonded Contract") with Vermilion & District Housing Foundation ("Vermilion") for the construction of an addition to and the modernization of an existing senior's lodge (the "Project"). Binder's scope of work included the supply and installation of resilient sheet flooring ("RSF") for the Project.

Binder obtained a performance bond (the "Performance Bond") issued by The Guarantee Company of North America ("GCNA"). The Performance Bond named Binder as principal, Vermilion as obligee, and GCNA as surety.

Following completion of the Project, problems were encountered with the RSF which had been installed. In 2006, an inspection of the RSF determined that excessive moisture from either groundwater or a high water table and hydrostatic pressure appeared to have forced moisture through the floor slab which was then trapped under the RSF, causing the adhesive to break down and the RSF to bubble and ripple.

After Binder and GCNA failed to provide Vermilion with any solution, in 2009 Vermilion installed weeping tile and replaced the defective RSF. In having that work carried out, Vermilion incurred substantial costs. Vermilion also suffered a loss of income as residents had to vacate the premises while the flooring was replaced.

Vermilion sued Binder, GCNA and others, advancing a number of claims including breach of the Bonded Contract and seeking recovery against GCNA pursuant to the Performance Bond. Vermilion sought to recover the costs incurred to install the weeping tile and to replace the RSF and recovery for its loss of income, however, the total amounts claimed were less than the penal sum of the Performance Bond.

II. HELD: Binder was held liable for 65% of Vermilion's damages for its negligence and breach of the Bonded Contract and GCNA was held liable under the Performance Bond for the amounts awarded against Binder, including loss of income.

The Court held the work of Binder was deficient, it breached its obligations under the Bonded Contract, and was negligent. The Court apportioned Vermilion's damages between Binder (65%) and the architect (35%). After some reductions in quantum, the Court awarded damages against Binder and the architect for the costs of the weeping tile, the cost of replacing the RSF, and the loss of income claimed. The Court held that GCNA's liability was co-extensive with that of Binder under the Performance Bond, including for the loss of income awarded.

On the liability of GCNA, the Court reiterated that when interpreting a performance bond, the Court must consider "the terms of the underlying contractual relationship and the degree to which the obligations outlined therein are incorporated into the bond by reference: APM Construction Services Inc v Caribou Island Electric Ltd, 2013 NSCA 62 at para 62, 330 NSR (2d) 182."

The Court noted there was conflicting case law on whether a surety could be liable for costs beyond the "bricks and mortar", such as liquidated damages or collateral money obligations found in bonded contracts:

[296] In Whitby Landmark Development Inc v Mollenhauer Construction Ltd (2003), 178 OAC 49, [2003] OJ No 4000 (CA), the Ontario Court of Appeal held that a surety is obliged to fulfill all of the defaulting contractor's contractual obligations, including collateral financial obligations such as profit sharing.

[297] However, in Lac La Ronge Indian Band v Dallas Contracting Ltd, 2004 SKCA 109, [2004] SJ No 531, the Saskatchewan Court of Appeal rejected the reasoning in Whitby Landmark Development Inc, holding that a surety's obligation is limited to completing the actual physical construction in the event of the contractor's default and does not extend to a financial guarantee of the payment of liquidated damages.

[298] In MGN Constructors Inc v AXA Pacific Insurance Co, 2013 ABQB 216, 21 CCLI (5th) 10, Graesser J., in obiter favoured the reasoning in Whitby Landmark Development Inc and opined that a surety could not arrange for completion of the contract in accordance with its terms and conditions unless it was responsible for any acceleration cost to meet the original schedule and any delay damages the owner was entitled to if the schedule was not met.

The Court then looked at the Performance Bond which set out four options open to GCNA in the event of a valid claim. The Court found GCNA was notified in a timely fashion of Binder's default, but noted neither Binder nor GCNA responded to the notice of default by Vermilion. The Court held that in failing to pursue options 1, 2, or 3, "GCNA elected, by default, to follow option 4; that is, to pay Vermilion the lesser of the Bond Amount or Vermilion's costs of completion, less the balance of the contract price."

The Court held it would have been within the reasonable contemplation of both Vermilion and GCNA that if it was necessary to remedy defects in Binder's work, then that remedial work might result in some loss of income to Vermilion: "...such losses would fall within the 'cost to complete' the work as set out in option 4 of the Performance Bond. Such costs fall within the indemnity obligations of Binder pursuant to the..." terms of the Bonded Contract.

The Court creatively sidestepped any difficulties posed by the schism found in the Whitby Landmark Development Inc and Lac la Ronge Indian Band decisions by distinguishing both:

[316] Whitby Landmark Development Inc concerned a provision requiring the contractor to pay the owner savings realized in carrying out the contract. Lac la Ronge Indian Band involved a provision entitling the Band to deduct liquidated damages for delay in completion of a sewage lagoon from the amount otherwise payable to the contractor. As Vermilion's loss of income in this case was directly related to the completion of the work, and was contemplated as such in the Construction Contract, I find this situation to be distinguishable from those in both Whitby Landmark Development Inc and Lac la Ronge Indian Band. Therefore, it is not necessary to comment further on the legal issues addressed in those cases.


This decision is of critical importance for the surety industry in Alberta (and other provinces) as it clearly expands the liability of a surety under a performance bond beyond the "bricks and mortar" costs of completing a defaulting contractor's obligations. While distinguishing both Whitby Landmark Development Inc and Lac la Ronge Indian Band, this decision clearly takes an approach consistent with Whitby Landmark Development Inc in that it finds a surety's liability is to fulfill all of the defaulting contractor's contractual obligations.

The Court distinguished both the Whitby Landmark Development Inc and Lac la Ronge Indian Band through characterizing Vermilion's loss of income claim as a "cost to complete", with those words placed in quotation and coming directly from the wording of the Performance Bond. Without any explicit analysis, the Court clearly interpreted these words to mean the "cost to complete the obligations of the principal under the Bonded Contract", as the Court expressly cited the indemnity obligations of Binder under the Bonded Contract for which it found the surety liable for.

The Court also held that the "loss of income in this case was directly related to the completion of the work". While the loss of income may have been related to the completion of the remedial work and the time take to complete the same, the perhaps more proper question to ask was: whether this loss of income was directly related to the deficiencies in Binder's initial work? In this author's opinion, the answer to this question is no.

Damages for loss of income are by definition "consequential" damages, in that they are not the normal loss which every obligee in a like situation will suffer (i.e. the "bricks and mortar" costs), but special to the circumstances of a particular obligee. Consequential losses are anything beyond this normal measure, such as profits lost or expenses incurred through the breach, and are recoverable if not too remote: McGregor on Damages, 15th ed. (London: Sweet & Maxwell, 1988).

The indemnity provisions at issue here are common in construction contracts. Any surety who issues a performance bond must now recognize that upon completion of a given project, should any warranty or indemnity obligations arise and the contractor fail to respond, then the surety may well be liable for not only the "bricks and mortar" costs to repair the work, but also any damages arising from the interruption of the business or operation of a given facility or project. These types of damages could add up very quickly leaving a surety exposed to the full value of the penal sum of a performance bond or even worse faced with an argument that the penal sum should not protect the surety as a result of its failure to adequately respond to a given warranty or indemnity claim being made pursuant to a performance bond.

Another important finding by the Court was with respect to the "default" selection of an option under the Performance Bond by GCNA. As mentioned above, both Binder and GCNA failed to provide any solution to Vermilion when the RSF issues arose. The Performance Bond gave GCNA four options in the event of Binder's default. Those options were:

  1. To remedy the default;
  2. To complete the Bonded Contract in accordance with its terms and conditions;
  3. To obtain a bid for submission to Vermilion for completing the Bonded Contract in accordance with its terms and conditions; or
  4. To pay Vermilion the lesser of the penal sum of the Performance Bond or Vermilion's proposed cost of completion, less the balance of the contract price.

GCNA did not elect which option it would pursue in response to Vermilion's claim. However, the Court found that by failing to make any election, GCNA elected, by default, to follow option 4; that is, to pay Vermilion the lesser of the penal sum of the Performance Bond or Vermilion's costs of completion, less the balance of the contract price.

This finding will be very helpful to sureties for if one were to fail to respond to a claim, this default option is likely the most favourable to a surety, as there is certainty about the limits of a surety's liability under this option. This finding will prevent an obligee from arguing it should get to choose an option which it might find preferential (and possibly accompanied with an argument from that obligee that in the circumstances the penal sum of the Performance Bond should not apply). The Court has also confirmed, albeit indirectly, that when a surety fails to respond to a claim, its liability remains capped by the penal sum of a performance bond, as a result of the "default" election to pursue option 4

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions