UK: Multi-Tasking - A Final Certificate That Is Also A Pay Less Notice (In Disguise?)

Last Updated: 24 January 2017
Article by Ashley R. Pigott

The notice provisions under the statutory requirements relating to payments under construction contracts are stringent. You need to be in a position to prepare valid notices and to recognise notices when they land.

The latest decision on these requirements reminds us that in terms of "Pay Less Notices", the intention of the sender together with the substantive content of the document will be determinative. The judgment presents an enlightening comparison of the different standards applied by the courts to the construction of payment and pay less notices and is worth considering in some detail.

The dispute was between Surrey and Sussex Healthcare NHS Trust (the Trust) and Logan Construction (South East) Limited (Logan). The Trust appointed Logan to carry out refurbishment and associated works at the East Surrey Hospital near Redhill in Surrey for approximately £4.4m under a JCT Intermediate Building Contract form with Contractor's Design 2011.

In purely financial terms, Logan considered it has an entitlement to a payment of approximately £1m whereas the Trust's position was that the balance due to Logan was approximately £14k.

Factual background

  • Practical completion of the works was certified on 25 August 2015 and the Final Certificate was due to be issued by 21 September 2016. The parties had numerous meetings to discuss the final account and scheduled one such meeting for 21 September 2016.
  • On 20 September 2016, Logan's QS, Mr Crook, sent an email to the Trust's QS (Mr Stone) headed "....Account Meeting 21st September 2016" attaching various documents, including a document headed "Interim Payment Notice" seeking payment of approx £1.1m (Logan's September IPN).
  • At the meeting on 21 September 2016, the final account valuation was discussed. The fact that Logan had issued a document entitled Interim Payment Notice was not discussed. No agreement was reached on the final account.
  • Later that day, Mr Stone sent an email to the Trust copied to Mr Crook entitled "...Final Certificate" appending various documents (which together, we will go on to refer to as the Trust's notification of 21 November for ease of reference below) which set out the Trust's position and resulted in a balance payable of approximately £14k (with a full breakdown).

    In his covering email, Mr Stone stated that he was attaching the Final Certificate, and the Adjustment of Contract Sum issued on 22 May 2016. Notably, he also stated "...on 20 September 2016 I received an Interim Payment Notice dated 24 August 2016 from Logan Construction. The last due date for an Interim Payment Notice under...the Building Contract was 24 August 2016 and as such the out of date and void. In any event, the details stated in the Final Certificate are the same as would have been stated in any final Interim Certificate which may have been issued...".

  • In November 2016, Logan was successful in an adjudication seeking payment of the sum set out in Logan's September IPN. By this time (anticipating the decision by the adjudicator), the Trust had commenced TCC proceedings seeking the declarations set out below.

The Declarations sought by the Trust:

  1. that Logan's September IPN was not a valid Interim Payment Notice; and
  2. that the Trust's notification on 21 November constituted a valid Pay Less Notice.

Was Logan's September IPN a valid Interim Payment Notice?

The Trust argued that Logan's September IPN was not valid as the parties were already engaged in final account discussions and at the meeting on 21 September, Logan's September IPN was not mentioned - thus (it was argued) the notice was not unambiguous and so, not valid.

Logan accepted that the covering email with Logan's September IPN was not as clear as it might have been but argued that the Notice document itself was clear in substance, form and intent. Also, the Trust's notification of 21 November had confirmed that Logan's September IPN had been received (which it was argued Mr Stone wrongly assumed was out of date and void).

TCC's Decision: Logan's September IPN was a valid Interim Payment Notice

The Judge considered it was notable that the Contract Administrator was in breach of the Contract by failing to issue an Interim Certificate on 24 August 2016 - this had led to the current dispute. It was no answer to say that the final account process overtook the need for the interim payment regime.

Logan's September IPN was an interim payment notice in substance, form and intent - it was clear and free from ambiguity.

Was the Trust's notification of 21 November a valid Pay Less Notice?

The Trust argued that the law relating to pay less notices is less prescriptive than for a contractor's notice. Although the primary function of the Trust's notification of 21 November was to issue the Final Certificate, in substantive terms, the notification contained all the relevant information required.

Logan argued that in order to be valid, the sender must objectively intend that the document should stand as a Pay Less Notice and there was no such intention (evidenced by the fact that Mr Stone had clearly stated in the Trust's notification of 21 November that he did not consider Logan's September IPN to be a valid payment notice).

TCC's Decision: the Trust's notification of 21 November was a valid Pay Less Notice

The Judge considered that nothing turned on the fact that the Trust's notification of 21 November was not addressed directly to Logan - it was cc'd to Logan and a box in a relevant pro forma had been crossed to confirm it had been issued to the contractor.

To constitute a valid Pay Less Notice, the notification had to specify the sum which the employer considered to be due at the date of the notice, and the basis of calculation. It was conceded by Logan that the Trust's notification of 21 November fulfilled both requirements.

The key issue in the Judge's view was not the substantive content of the document (which was agreed to be "compliant" in any event) but whether or not Trust's notification of 21 November was intended to constitute a Pay Less Notice. The Judge agreed that such intention was "an essential requirement" but said that "that intention must be derived from the manner in which it would have informed the reasonable recipient". His conclusion was that "..... on a broader level, one intention of [the Trust's notification of 21 November] was that it should be responsive to the Interim Payment Notice".

Drawing from previous caselaw, the Judge stated that the Trust's notification of 21 November provided "an adequate agenda for an adjudication as to the true value of the Works on an interim basis for the purposes of [that Valuation]".

Further notable points on validity were as follows:

  • The valuation date referred to in the Trust's notification of 21 November was different to that stated in Logan's September IPN - it was accepted that this was not enough to invalidate it. The amount to be paid pursuant to a Pay Less Notice under the Contract was to be determined at the date the notice was given - ie the valuation did not have to be made at the due date for payment.
  • The Judge saw no difficulty with the idea of serving a contingent Pay Less Notice ie the Judge took the approach that effectively, in his email of 21 November, Mr Stone was saying: I consider Logan's September IPN to be invalid but if it is not, here is a Pay Less Notice. The Judge said that Mr Stone's secondary intention in issuing the Trust's notification of 21 November was to rely on the Pay Less Notice if he was wrong about the invalidity of the Interim Payment Notice.
  • There was no reference to "Pay Less Notice" or the pay less notice clause in the Contract anywhere in the Trust's notification of 21 November - nevertheless, the question was whether, viewed objectively, it had the requisite intention to fulfil that function; it did.

Content or Intention?

As was emphasised in this case, "draconian consequences.. .flow from a failure to serve a compliant Pay Less Notice in response to an Interim Payment Notice". If you are in a position where you may receive a pay less notice, always be aware that (subject to the terms of the relevant contract) any documents you receive from the paying party setting out their view and breakdown of the sum due may constitute a valid pay less notice, even if there is no overt suggestion on the face of the documents that they are so intended.

In light of this judgment, we suspect that many parties currently in the throes of a payment notice dispute will be hurriedly revisiting relevant communications with fresh eyes, to ascertain whether or not they can (arguably) be relied upon as constituting a valid pay less notice.

If the substantive content of those documents can be demonstrated to be "compliant", one might argue that a paying party is almost home and dry, as based on this decision, even demonstrating a secondary and contingent intention to issue a pay less notice may be sufficient.

If the content is compliant ("containing all the material information which should be conveyed by a Pay Less Notice"), a party expecting payment may find that the task of seeking to demonstrate the absence of any such secondary intention to issue a pay less notice surprisingly arduous.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Events from this Firm
22 Nov 2017, Seminar, Montreal, Canada

Please join us on Wednesday, Nov. 22 for a breakfast seminar featuring a panel of experts who are abreast of the most recent developments in the field. Also featured will be Paul Allard, president of Impak Finance, who launched the first cryptocurrency offering under the traditional financial regulatory framework.

29 Nov 2017, Seminar, London, UK

Join us at 4 More London for this breakfast seminar on Wednesday, 29 November 2017 to gain a greater understanding on this debate. Coffee and breakfast will be from 08:30 with the discussion commencing at 09:00. We will finish and have you on your way by 10:00.

7 Dec 2017, Seminar, London, UK

Would you like the opportunity to hear more about the potential disruptive effect that blockchain is going to have in the energy sector? If so, please join us on 7 December where Jo-Jo Hubbard, a leading light in this area, will explain all.

In association with
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.


Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.


Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.


A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.


This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.


If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.


From time to time Mondaq may send you emails promoting Mondaq services including new services. You may opt out of receiving such emails by clicking below.

*** If you do not wish to receive any future announcements of services offered by Mondaq you may opt out by clicking here .


This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at and we will use commercially reasonable efforts to determine and correct the problem promptly.