Algeria: Renewables In Algeria: Overview Of The New PPA For Solar PV And Wind

Last Updated: 31 December 2015
Article by Eric Diamantis, Julien Barba and Pierre Ferroud

The final templates of the Algerian Power Purchase Agreement (PPA) for PV solar and wind projects have just been published by the Algerian electricity and gas regulator (CREG), along with a set of decisions completing the renewable regulatory package.

As indicated in our previous briefings dated December 2014 and April 2015, the CREG has finally published the set of regulations required for Developers to initiate and develop PV solar and wind projects in Algeria.

WHAT'S NEW SUMMARY
PPA Template for PV solar and wind projects The PPA templates for PV solar and wind projects have been issued by a decision of the CREG dated 17 May 2015 and are made up of (i) general terms and (ii) specific terms for both PV solar and wind projects installations which are to be developed under the Specific Regime, which aims to provide a specific framework to renewable energy projects, settled by Decree No.13.218, dated 18 June 2013.
Feed-In Tariff (FiT) application forms Two separate application forms, one each for PV solar and wind projects, for requesting the FiT granting decision have been published by two decisions from the CREG dated 10 and 17 May 2015. The FiT granting decisions approve the right to benefit from the FiT and enter into the PPA.
Certificate of Guaranteed Origin (CGO) Two application forms, one each for PV solar and wind projects, for requesting the CGO have been published by two decisions from the CREG dated 10 and 17 May 2015. The CGO is a pre-requisite for the request of the FiT decision.
Data collected from the measurement systems This decision provides the information which has to be transmitted by the IPP to the CREG during the operating of the plant, on a monthly and annually basis.
WHAT'S NEXT SUMMARY
CREG regulations on templates for grid connection and injection agreements These regulations shall approve the templates of the grid connection agreements, applicable to the IPP, to be entered into between the Developers nad the DSO. They are still missing and shall be published on the CREG / Distribution System Operators (DSOs) website. Entering into the grid connection agreement is a pre-requisite to the commissioning of the plant as it determines the terms and conditions of the electricity injection on the electricity grid.
CREG regulations on financial compensation of the DSOs and the Algerian electricity transport operator (GRTE) and on the average electricity price These regulations should be issued by the CREG soon and will be published on the CREG website.

MAIN FEATURES OF THE PPA

Project Eligibility

Eligible renewable projects must have the following: an installed power capacity greater than 1MW; a certificate of guaranteed origin; operating authorisation to generate electricity from a renewable energy source; be connected to the distribution or transmission grid; be eligible to the Specific Regime and to the insurance of the FiT granting decisions. The DSO is then required by law to enter into PPAs with a renewable Developer and to connect its plant to the electricity grid.

Separate signing and entry into force

The signing date and the entry into force of the PPA have been distinguished in practical terms. The PPA shall be signed and executed before the construction phase starts and shall help to secure financing (in any case after the granting of the FiT granting decision). The PPA shall enter into force only from the commissioning date of the plant. The commissioning date of the plant is defined as the commissioning date of the data system measurement. Some other conditions are imposed by the PPA for its entry into force, such as the validation of the commissioning tests of the power plant and the measurement systems.

Duration of the PPA

The PPA will be executed for 20 years as from the commissioning date of the plant. However, this initial 20 year term can be reduced if the commissioning date of the plant occurs more than six months after the expected commissioning date indicated in the PPA, as a result of the IPP action or inaction. The PPA duration should be then reduced proportionally to the delay.

Amount of the FiT and its adjustment

The applicable FiT in the PPA shall be the one mentioned in the applicable Ministerial Tariff Order in force at the date of the FiT granting decision.

The FiT will however be adjusted after the first five years of operation of the plant, after comparison between (i) the real operating hours of the plant measured during this five year period and (ii) the reference operating hours, of 1,500 hours, used as reference for the first five years. The applicable FiT for the first five year period is based on a reference base of number of operating hours ("Phase 1" is equal to 1,500 hours for every IPP), while the following 15-year period shall be based on the real operating hours corrected after Phase 1. In any case, the adjusted FiT shall not vary of more than 15% from the initial FiT.

The FiT adjustment after five years shall give rise to an amendment to the PPA.

Take-or-pay

DSOs are obliged to take all the electricity produced and injected by the plant, and pay for it, except in the case of (i) Force Majeure and (ii) unavailability to take the production.

The first case, Force Majeure, is defined as "any act or event unforeseeable, irresistible and independent from the will of the Parties" without any further description.

The second case, unavailability to take the production, is defined as:

  • Scheduled unavailability of the grid, when it has been scheduled and agreed between the parties;
  • Unscheduled unavailability of the grid, when it does not exceed a total sum of 24 hours per year. Beyond this 24-hour limit, the electricity produced but not injected shall be paid on the FiT basis.

Amount of production purchased

The amount of the electricity purchased under the FiT is limited. Beyond a certain threshold (threshold determined as the number of operating hours multiplied by the installed peak capacity of the plant), the electricity produced will be purchased at a price "equal to the average price of conventional electricity on the Algerian market", with no fixed price.

Billing and payments

The billing and the relevant payments will be executed on a monthly basis, and the DSO will be required to pay the power producer within 30 days from receipt of the relevant invoice. The payments will be made in Algerian Dinars (DA).

Comments on the PPA

The publication of this new set of regulations confirms that Algeria is committed to the development of renewable energy projects. However, with regard to the PPA itself, specific points should be reviewed and addressed with the relevant public authorities in order to ease the implementation of renewable energy projects. Some of these points are proposed below:

  • The entry into force of the PPA is subject to a list of Condition Precedent which are, at this date, not clearly defined and limited. These CPs can bring some uncertainty to the Developers (for example Article 6 relating to the "presentation of the applicable permits and authorisations"). Additionally, there might be a risk that this list of CPs is contradictory with the Executive Decree on the PPA which provides that the PPA enters into force only at the commissioning date of the plant, without any other additional condition.
  • The PPA duration reduction is triggered if (i) the plant is commissioned later than six months after the expected commissioning date and (ii) if this delay is caused by the power producer. The PPA remains silent on the delays which would be caused indirectly by the Administration, the DSO or the certification bureau for example (delays in the issuance of a required authorisation, in the validation of the tests, etc.). Should it be considered as a delay caused by the power producer, would this leave the Developer to bear the PPA reduction delay without any compensation?
  • Credit worthiness of the regional DSOs until the term of the PPAs. The DSO, which is holding a long-term license by the State for operating the distribution grid, represents and warrants in the PPA that it has the financial and legal capacity to enter into such agreement for the entire 20 year duration. Does the DSO have the financial robustness and capacities to enter into long-term PPAs? How will the DSO be funded?
  • The clause for Force Majeure is not defined with sufficient precision and therefore shall be interpreted in light of common case law – this can raise a number of uncertainties for the Developer. The initial drafting of this clause under the PPA circulated by the CREG as a base for negotiation was more detailed. How should the Force Majeure clause be reinstated in order to reduce this legal uncertainty?
  • The risks of suspension and termination of the PPA are quite wide although they are limited in number. Pursuant to the PPA, the PPA can be suspended or terminated in the case of (i) suspension or termination of the and (ii) suspension or termination of the FiT granting decision. Firstly, how should be managed the PPA execution in case of suspension of the operating authorization or the execution of the related grid connection agreements? Second, the causes of suspension and termination of the CGO and the FiT granting decision should be thoroughly reviewed.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Similar Articles
Relevancy Powered by MondaqAI
 
Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions