United Arab Emirates: Construction Claims: Recovering The Costs Of Additional Preliminaries

Last Updated: 17 February 2011
Article by Dean OLeary

Part 1

Those involved in the region's construction industry will be well aware that over the last couple of years there has been a rapid expansion in the number of construction claims and disputes.

A head of claim that is often made by contractors against employers is for prolongation costs, i.e., those costs sought by a contractor for having to remain on site longer than it originally anticipated due to the actions of an employer.

Much has been written about the recoverability of head office overheads and, more specifically, whether such claims can be proven by way of reliance on a formula or whether actual cost data is required.

However, an important aspect of prolongation claims that is often not addressed by commentators on construction claims is the basis and evaluation of claims for additional preliminaries (or job site overheads as they are known in the United States). In short, preliminaries are comprised of fixed costs, time related costs, activity related costs and value related costs.

This article seeks to provide a brief overview of what to be mindful of when making or facing a claim for additional preliminaries.

When faced with any claim, an employer should always remember that the onus is on a contractor to demonstrate (i.e, prove) its entitlement to the relief being claimed. In short, it is not for an employer to disprove a contractor's claim; rather, it is for a contractor to prove its claim, both in terms of liability and quantum: he who asserts must prove. As basic as this restatement of the underlying principle of construction claims is, it is surprising how often it is overlooked by employers, contractors and their advisers.

All too often, and despite express contractual provisions that require the timely submission of detailed claims, a contractor will submit a claim for prolongation costs as part of its final account exercise and simply assert that because it suffered an employer caused delay to a critical activity (or series of activities) during the progress of the works the original completion date was missed; hence, it claims for its costs associated with its prolonged presence on site until such time as the works were finally completed. In theory, and provided the employer was responsible for any critical delay, there is no problem with bringing such a claim (subject, that is, to satisfying any procedural requirements). The problem, however, usually arises out of the contractor's method of valuing its losses arising from its prolonged presence on site.

It is common for a contractor to value its claim for additional preliminaries on the basis of the period that a project has overrun, i.e., from the original completion date to the actual completion date, by simply relying upon its preliminaries at the end of original contract period and continuing them during the extended period. This type of claim is colloquially known as a 'pro rata prelims claim'.

However, an employer may be ill advised to make payment of a contractor's prolongation costs claim on the basis of a pro rata prelims claim. Similarly, a contractor may be short-changing itself by claiming for its additional preliminaries in this way.

Whilst there may be occasions when the early settlement of a contractor's claim is commercially viable, it should be noted that a pro rata prelims claim is likely to be either inappropriate or wrong for the reasons set out below.

The first reason why a pro rata prelims claim is wrong is because it is dealing with the wrong period. A claim for additional preliminaries should be assessed at the date of the breach itself, i.e., when the delays actually occurred. Take a simple example, a small project has a 3-month contract period and during the first month delays occur which delay the final completion date by a further month. In this scenario the appropriate period for assessing the preliminaries to be claimed is the first month, i.e., the period when the delays actually occurred, and not the extended month.

Unfortunately, this problem is often compounded by reason of the fact that an employer will often pay a contractor for all of the claimed preliminaries over this delayed period without making an adjustment for the contractor's actual progress. By making such payment the employer exposes itself to a financial risk later in the project because at some future point all of the activity and time related preliminaries included in the contract price will have been paid by the employer, but the contractor will have not completed the works.

Another potential problem with pro rata prelims claims is the risk of double recovery. In short, if the cause of a delay to a project's completion has been the issuance of variations or the carrying out of dayworks then the employer should ascertain if the cost of additional preliminaries for carrying out those variations or dayworks has been included within the valuation of the same (though, this tends to be more of an issue in terms of a claim for head office overheads and profit). Therefore, employers should carefully scrutinise a pro rata prelims claim which is based on delays caused by variations.

A further potential problem with pro rata prelims claims (leaving aside arguments that the preliminaries figures in the Bill of Quantities may not represent a contractor's actual costs when the works are carried out) is that a contractor will often fail to apportion those costs included within its activity or time related preliminaries between those which are recoverable as part of a claim and those which are not. In other words, if a delay is suffered to a critical activity it may well be that some aspects of the overall preliminaries can still be put to good use on other activities during this period of delay. In a recent English case the risks of a party failing to properly apportion its preliminaries in this way were made all too apparent. In this particular case the learned Judge had this to say on the point:

"But the contractor will not recover the general site overheads of carrying out all activities on site as a matter of course unless he can establish that the delaying event to one activity in fact impacted on all the other site activities. Simply because the delaying event itself is on the critical path does not mean that in point of fact it impacted on any other site activity save for those immediately following and dependant upon the activities in question... But no evidence has been called to establish that the delaying events in question in fact caused delay to any activities on site apart from [critical buildings]. That being so, it follows, in my judgment, that the prolongation claim advanced by [the Claimant] based on recovery of the whole of the site costs of the [project] site, fails for want of proof."

The Claimant, or more properly its quantum expert and legal team, had failed to make any attempt to apportion between the preliminaries associated with those activities which were on the critical path and those which were not.

It is suggested that the above proposition of apportioning preliminaries ties in with the UAE principle of proof of damages. That being said, it is acknowledged that there may be circumstances in a particular case where no such apportionment can or need be carried out.

What is also interesting to note about this particular case is that when proceedings commenced the Claimant sought to recover GBP3.5million. However, during the course of proceedings it reduced its claim to GBP1.5million (for which the learned Judge believed the Claimant had exaggerated its initial claim and this had subsequent implications in terms of recovering its legal costs). The Claimant was actually awarded GBP163k! Given that the Claimant's legal costs in the case were approximately GBP1.6million and that the Defendant was ordered to pay approximately 40% of the Claimant's costs one can see how this became somewhat of a pyrrhic victory for the Claimant.

In summary, employers and their advisers should be wary of entertaining pro rata prelims claims. The onus is always on a contractor to prove its entitlement to a claim both in terms of liability and quantum. Clearly, if a contractor has suffered a loss then, as a matter of law, it should be compensated, but only insofar as it is able to properly demonstrate its loss.

NB: The above article does not constitute, and should not be interpreted or relied upon, as legal advice.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions