United States: O Ye Of Little Faith: Breaching The Duty Of Good Faith And Fair Dealing While Complying With The Express Terms Of A Government Contract

In contracts – and especially in government contracts, where one is expected to "turn square corners" – we often analyze breach of contract in light of the jots and tittles of a contract's express terms.  And, in bringing a Contract Disputes Act (CDA) claim against the Government based upon an alleged breach, one's focus usually (and rightly) is on the express terms of the contract.  In a recent decision, however, the Court of Appeals for the Federal Circuit reminded us that a contract can be breached even if the parties scrupulously adhere to every one of the contract's written terms.

In Agility Public Warehousing Co. KSCP v. Mattis, 852 F.3d 1370 (Fed. Cir. 2017), the Federal Circuit considered an appeal involving a logistics contract for delivering food and non-food goods overseas.  Before the Armed Services Board of Contract Appeals, the contractor had argued that the Government breached the express terms of the contract by using the contractor's trucks for storage and failing to consider requested exceptions to the contract's 29-day cap on the number of days for which the Government would pay transportation fees.  The contractor also argued the Government breached the contract's implied duty of good faith and fair dealing by failing to cooperate in the contractor's performance, and imposed constructive changes upon the contract.  The Board ruled that the Government had not breached the contract's express terms and, therefore, the Board "need not decide whether the government constructively changed contract performance or whether it breached its implied duty of cooperation" because "whether the government breached the contract comes down to contract interpretation."

Although the Federal Circuit upheld the Board's ruling that the Government did not breach the contract's express terms, it vacated the Board's judgment on the breach of implied duties and constructive changes.  Citing its precedent in Metcalf Constr. Co. v. United States, 742 F.3d 984 (Fed. Cir. 2014), the Federal Circuit held that a "breach of the implied duty of good faith and fair dealing does not require a violation of an express provision in the contract."  The court accepted the contractor's argument that, even if the Government strictly adhered to the text of the contract, it may have breached implied contractual duties by "inter alia, interfering with Agility's ability to perform its duties under the contract by unnecessarily delaying the return of Agility's trucks and not increasing its on-site food storage capabilities" or "simultaneously impos[ing] a cap and engag[ing] in conduct that made it impossible for Agility to perform within that cap."  The Board's decision on the breach of express terms, in other words, was not dispositive of the contractor's remaining claims.  Without deciding the merits of the claims, the court held that the Board erred by failing to analyze the alleged breach of implied duties (as well as the constructive changes claim) and remanded to the Board for further proceedings.

The implied duty of good faith and fair dealing (which embraces the duty to cooperate and not to hinder the other party's performance) does not "expand" a party's contractual duties or create duties inconsistent with the express terms of the contract.  It does, however, require the parties to cooperate in performance and not act in a way that destroys the other party's reasonable expectations of the benefits provided by the bargain.  The Federal Circuit cited with approval the Restatement's examples of breaches of the implied duty, including "evasion of the spirit of the bargain, lack of diligence and slacking off, willful rendering of imperfect performance, abuse of a power to specify terms, and interference with or failure to cooperate in the other party's performance."  Restatement (Second) of Contracts § 205 cmt. d.

Although the Agility court did not address the issue, it is worth adding that a failure to act in good faith is not necessarily the same as acting in bad faith.  See, e.g., Metcalf Constr., 742 F.3d at 993 (holding that "specific targeting" of a contractor is not required to show a breach of the duty of good faith and fair dealing); CanPro Investments Ltd. v. United States, 130 Fed. Cl. 320, 350 (2017) ("[A plaintiff] is not required to plead and prove bad faith on the part of the [Government] to succeed on its claim for breach of the implied duty of good faith and fair dealing."); Tecom, Inc. v. United States, 66 Fed. Cl. 736, 770 (2005) (holding that bad intent is not a necessary element in showing a breach of the implied duty to cooperate and not hinder performance); see also SupplyCore, Inc., ASBCA No. 58676, 16-1 BCA ¶ 36,262 ("A showing of bad faith is not required to demonstrate a breach of the duty [of good faith and fair dealing].").  This distinction is important because the burden of proof for showing a Government official acted in bad faith is notoriously high.

In the end, it is not easy to prevail on a claim of breach of the duty of good faith and fair dealing, and it is not clear whether Agility will prevail on the merits of its claim when the Board takes it up again on remand.  The Federal Circuit's reaffirmation of the continuing validity of this legal theory, however, means contractors that have been demonstrably harmed by their Government customer's unreasonable actions may have a path to recovery under the CDA, even if they cannot identify a particular contract clause that the Government has violated.

Because of the generality of this update, the information provided herein may not be applicable in all situations and should not be acted upon without specific legal advice based on particular situations.

© Morrison & Foerster LLP. All rights reserved

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Similar Articles
Relevancy Powered by MondaqAI
Eckert Seamans Cherin & Mellott, LLC
In association with
Related Topics
Similar Articles
Relevancy Powered by MondaqAI
Eckert Seamans Cherin & Mellott, LLC
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions