United States: You Gotta Fight… For Your Right… To Early Completion

Last Updated: October 15 2015
Article by Carly Miller

In Gilchrist Constr. Co., LLC v. Louisiana Dep't of Trans. and Dev., a Louisiana appellate court recently confirmed that a contractor was able to demonstrate delay damages due to a critical path delay based on increased work requirements even though the contractor was ultimately able to finish the project ahead of schedule. The project involved the widening of an interstate highway for the Louisiana Department of Transportation and Development. Gilchrist, the contractor, finished the project ahead of schedule and was paid the contract price, including additional compensation for change orders and an early completion bonus. The principal issue was the recoverability of delay costs for a dispute concerning the scope of work and what the contractor alleged to be the state's gross miscalculation of the quantity of embankment required for the project. Gilchrist alleged that, but for the state's gross miscalculation, it would have bid 180 more days. The trial court rendered judgment in favor of Gilchrist, and the state appealed.

The principal issue on appeal was whether Gilchrist properly proved that it incurred delay damages because of the increased quantities of embankment and lime used for the project. A cost-plus-time bidding procedure was used to bid and award the project, which takes into account not only the contract amount but also the contract time required for completion. The contract amount bid was the summation of the quantities shown in the Schedule of Items in the contract multiplied by the unit prices. The records established that (1) Gilchrist placed over sixty thousand cubic yards of additional embankment material (forty percent increase) than what was advertised in the requests for proposal; (2) Gilchrist accomplished the items of work required to complete the project in less time than was bid or required under the contract; (3) the state paid Gilchrist for the additional embankment materials, and (4) Gilchrist was also paid the maximum amount possible as an early completion bonus. The state argued that under the terms of the contract, Gilchrist was fully and completely compensated for any additional work caused by the increased quantities of embankment and lime. Gilchrist, however, asserted that it had incurred damages due to the delay in the project caused by placement of extra material, despite being compensated for the extra quantities.

Critical to determining whether Gilchrist was entitled to such compensation was a determination whether Gilchrist sufficiently proved that the increased quantities actually delayed the project. As proof that a delay of the project occurred due to the forty percent increase in embankment and thirty percent increase in lime, Gilchrist used its initial, baseline Critical Path Method ("CPM") schedule to show that the placement of the extra material delayed the project by 180 days. The state argued that the way by which Gilchrist used the baseline schedule to calculate whether the project was delayed was improper and incorrect. The contract contained a provision regarding CPM scheduling requiring submission of schedules in a prescribed method. Because the CPM schedule was not updated by Gilchrist in advance of the extra quantities being incorporated into the work, one of the state's scheduling experts rejected the retroactive calculation of the time impact using the baseline schedule. The expert testified that the best and most proper evidence of the facts was the culmination of all the updated CPM schedules prepared by Gilchrist as the work progressed. The only evidence of the 180-day delay claimed by Gilchrist was the impacted CPM schedules Gilchrist generated based on modifications of the baseline schedule.

There was testimony at trial that it had always been Gilchrist's intention to finish the project early. The production rate calculated for purposes of Gilchrist's bid and the actual production rate that occurred in performing the work were quite close and both greatly exceeded the production rate projected in the baseline schedule. Gilchrist put on testimony that it performed the embankment work at the accelerated production rate because of the state's refusal to grant any extra time for the additional quantities of embankment, and that it was compelled to increase its production rate to avoid the threat of liquidated damages in the event that the extra quantities caused it to fall behind schedule.

The appellate court found that the trial court did not err in accepting the impacted baseline as evidence of delay caused by the increased quantities of embankment and lime. This holding is not found in all jurisdictions; other courts have held that because a contractor failed to follow the schedule specification, it could not support its delay claim. In this case, both the lower court and the appellate court determined that Gilchrist sufficiently proved that its planned early completion of the project was delayed due to increased quantities of material. Gilchrist was, therefore, entitled to recover the damages it incurred as a result of the delay.

The court found that whether the contractor's increased production rate was a result of trying to avoid the threat of incurring liquidated damages or was simply a manifestation of Gilchrist's intention to complete as early as possible, the fact remains that the contractor performed the work at a rate that was faster than required by contract. In the construction industry, a contractor has the right to finish early, so long as that plan is expressed in advance of performing the work, generally through a baseline schedule showing early completion. Contractors should keep this principle in mind—that even if it completes a project ahead of the requirements in a contract, it may be entitled to damages resulting from the delays caused by the Owner to an early completion schedule.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions