United States: Federal Grant & Contract News for Nonprofits - October 2013

Last month  we provided information on the guidance given by the U.S. Office of Management and Budget ("OMB") as the federal government (the "Government") prepared for the Government shutdown (the "Shutdown"). Since that time, the government did indeed partially shut down and finally after 16 days, reopened. With the Shutdown behind us, what should and can your nonprofit be doing to recover costs incurred under your contracts during that time?

Please keep in mind that the following constitutes general guidance rather than specific advice to the impact of the Shutdown on your particular contract(s). Your particular situation will depend on fact-specific circumstances and the language contained in your contract with the relevant Government agency.

What rights do I have to recover costs due to the Shutdown if my nonprofit organization was issued a stop-work order?

Under a stop-work order, you are generally entitled to receive reasonable costs incurred, however, the type of contract at issue also may have an impact on what you may be able to recover. Under a firm fixed price contract, you may have grounds for asserting the full amount of your contract. However, this determination will depend upon the specific terms of your contract. At a minimum, you should be entitled to recover reasonable and necessary costs incurred due to the unforeseen Shutdown, such as demobilization and remobilization costs or possible idle labor costs. It is important to be careful when submitting an invoice to the Government for full compensation under a firm-fixed price contract because it could be construed as invoicing the Government for work not actually performed and, as a result, lead to allegations of fraud. Absent clear language in the contract, any invoice submitted to the Government should only reflect the amount of work actually performed at the fixed unit price. This may require you to submit an invoice for the proportional amount of the fixed price based upon the work actually performed, if any. To recoup the difference between the proportional amount and the contract amount, or other costs associated with the Shutdown, contractors should submit a request for an equitable adjustment ("REA") or a claim to ensure that you are fully compensated and do not underwrite the Government's Shutdown. Conversely, under a cost-reimbursement contract, you would be precluded from asserting the full anticipated amount of the contract and would likely be limited to only those reasonable costs incurred due to the Shutdown, such as demobilization and remobilization costs, and possibly idle labor costs.

What costs are reimbursable as a result of the Shutdown?

Unmitigable and reasonable costs incurred due to the Shutdown generally should be reimbursable. In order to recover these costs because of the Shutdown, contractors must be able to demonstrate that the cost impact occurred and tie the impact to the Shutdown. Employees that are prevented from performing work, therefore, should provide detailed time entries and record their labor costs in segregated accounts to demonstrate the idle or other labor costs of the Shutdown. Other cost impacts, such as costs associated with rescheduling work or deliveries, or increased supplier prices, should be similarly documented.

How should I invoice the Government for my contract during the Shutdown?

It is important to be careful when submitting an invoice to the Government for full compensation under a firm-fixed price contract because it could be construed as invoicing the Government for work not actually performed and, as a result, lead to allegations of fraud. Absent clear language in the contract, any invoice submitted to the Government should only reflect the amount of work actually performed at the fixed unit price. This may require you to submit an invoice for the proportional amount of the fixed price based upon the work actually performed, if any. To recoup the difference between the proportional amount and the contract amount, or other costs associated with the shutdown, contractors should submit an REA or a claim to ensure that you are fully compensated and do not underwrite the Government's shutdown.

Similarly, for cost-reimbursement contracts, contractors should submit an invoice that reflects the costs and markups associated with the work actually performed. Conversely, however, under a cost reimbursement contract, a claim to recover the full anticipated contract value would be difficult given the nature of cost-reimbursement contract.

What if the Government refuses to pay (in full or in part) my nonprofit organization for work performed during the Shutdown?

If the work was funded throughout the period of the Shutdown (i.e., the contract did not expire or the contractor has not assumed that an option would be exercised), depending on the circumstance, the contractor should consider filing an REA or a claim.

What if the Government rejects my invoice and stipulates to partial payment due to the Shutdown? For instance, what if my employees were available and ready to work, but could not access Government premises to perform services under a fixed-price contract? If I paid those employees who did not actually work, can I charge the Government for that payment?

Under a stop-work order, you would likely be precluded from asserting the full amount of the contract, however, you would be able to assert reasonable costs incurred due to the Shutdown, such as demobilization and remobilization costs, and possibly idle labor costs.

If you did not receive a stop-work order and your employees were ready and available to work under the firm-fixed price contract, there may be an argument, dependent upon the specific terms of each contract, that the contractor is the beneficiary of these circumstances and therefore the total price due under the contract should not be reduced simply because of the Government shutdown. Firm-fixed price contracts are designed to place risk on the contractor for cost overruns, but contractors are entitled to benefit when costs are less than anticipated. Alternatively, the Government could assert its defense as a sovereign, releasing it of liability. Thus, the most conservative course of action, because of concerns over fraud (e.g., possibly misrepresenting that you performed work when you did not during the Shutdown), would be to submit an invoice for the proportional amount of the fixed price based upon the work actually performed, followed by an REA or a claim for the difference, as well as any additional costs incurred as a result of the Shutdown.

Is it different if this situation occurs under a cost-reimbursement contract?

The situation is no different if a stop-work order has been issued. However, if a stop-work order has not been issued, the situation differs greatly because, by the terms of the contract, the contractor is only entitled to those reasonable costs incurred. As a result, the contractor would only be able to seek those costs incurred after taking steps to mitigate such costs.

Are there other theories of recovery if I did not receive a stop-work order?

Yes. FAR 52.242-17, the Government Delay of Work clause, entitles contractors to an adjustment to their contract for Government-caused delays. However, for a contractor to assert delay claims, the contractor must file its claim within 20 days of when the delay costs were incurred, or "as soon as practicable after the termination of the delay or interruption." Given this language, if a contractor is not subject to a stop-work order, thereby foreclosing its right to "stop-work order" costs, the contractor may seek to assert an adjustment under the theory that the Government Shutdown resulted in additional costs due to the delay of work. To do so, the contractor would need to file its claim within 20 days of when the costs were incurred (e.g., the Shutdown took place on October 1, therefore a claim to recover all costs would need to be filed by October 21), or as soon as practicable following the delay (i.e., the Shutdown). Even if you cannot immediately quantify your claim, it is important that you promptly notify the contracting officer in writing that the Shutdown delayed or interfered with your work, the delay increased your cost or will have an impact on your schedule, and that you will be submitting a claim when the costs are fully quantified.

Additionally, the FAR's Changes clause (FAR 52.243-1, Changes—Fixed Price, 52.243-2, Changes—Cost Reimbursement, 52.243-3, Changes—Time-and-Materials or Labor-Hours, 52.243-4, Changes) allows contracting officers to make changes to a contract, by written order, at any time. Although it is unlikely your contracting officer characterized an order to suspend work (or other Shutdown-related orders) as a "change" to the contract schedule, such a significant interruption arguably constitutes a change to the contract. If you want to preserve your right to any claim on the basis that the Shutdown was a "change" (in addition to a claim under the stop-work order or Government Delay clause), assuming one of the above-cited changes clauses was contained in your contract, you must assert your right to an adjustment (such as an increase in the price or a revision to the performance schedule) within 30 days of the receipt of a written change order. If you did not receive an explicit "change order," the 30-day clock likely begins as soon as you received written direction relating to the Shutdown, or possibly the start of the Shutdown itself.

Given that an order may have been issued prior to the Shutdown, contractors' time for requesting an adjustment to the contract is likely accruing and the 30-day deadline approaching. Again, due to the potentially truncated timeline under your contract's Changes clause, you may need to quickly consider whether you will be seeking recovery under this FAR provision.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration
Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:
  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.
  • Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.
    If you do not want us to provide your name and email address you may opt out by clicking here
    If you do not wish to receive any future announcements of products and services offered by Mondaq you may opt out by clicking here

    Terms & Conditions and Privacy Statement

    Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

    Use of www.mondaq.com

    You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

    Disclaimer

    Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

    The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

    Registration

    Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

    • To allow you to personalize the Mondaq websites you are visiting.
    • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
    • To produce demographic feedback for our information providers who provide information free for your use.

    Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

    Information Collection and Use

    We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

    We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

    Mondaq News Alerts

    In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

    Cookies

    A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

    Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

    Log Files

    We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

    Links

    This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

    Surveys & Contests

    From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

    Mail-A-Friend

    If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

    Emails

    From time to time Mondaq may send you emails promoting Mondaq services including new services. You may opt out of receiving such emails by clicking below.

    *** If you do not wish to receive any future announcements of services offered by Mondaq you may opt out by clicking here .

    Security

    This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

    Correcting/Updating Personal Information

    If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

    Notification of Changes

    If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

    How to contact Mondaq

    You can contact us with comments or queries at enquiries@mondaq.com.

    If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.

    By clicking Register you state you have read and agree to our Terms and Conditions