UK: Taking Over: The Meaning Of Completion Under The 2017 FIDIC Contracts

Last Updated: 4 September 2019
Article by Jesse Way

In December 2017, FIDIC released the second editions of the Red, Silver and Yellow Books ("the 2017 FIDIC Contracts").

At the end of March 2019, the Court of Appeal in England and Wales delivered judgment in Mears Ltd v Costplan Services (South East) Ltd & Ors [2019] EWCA Civ 502 ("Mears").

In Mears, the Court of Appeal considered issues relating to material breaches of contract and practical completion. Judging when a project is complete, or suitable for taking over, is not always straightforward, and the Mears case provides a useful opportunity to consider the meaning of "completion" under the FIDIC Form and elsewhere.

Completion under the 2017 FIDIC Contracts

The Red and Yellow Books are administered by an Engineer whereas the Silver Book is administered by the Employer or the Employer's Representative.

The Date of Completion across all three books, whilst drafted in slightly different terms, essentially means the date stated in the Taking-Over Certificate issued by the Engineer or Employer, or, if applicable, the date on which the Works or Section are deemed to have been completed. Only the issue of the Taking-Over Certificate will be examined in this article.

The Taking-Over Certificate is issued, or deemed to have been issued, in accordance with Clause 10 (Employer's Taking Over). To summarise the process relating to the issue of a Taking-Over Certificate under Clause 10:

1. The Contractor may apply for a Taking-Over Certificate by giving a Notice to the Engineer or Employer not more than 14 days before the Works or Section will, in the Contractor's opinion, be complete and ready for taking over.

2. Within 28 days after receiving the Contractor's Notice, the Engineer or Employer shall either:

a. issue the Taking-Over Certificate to the Contractor, stating the date on which the Works or Section were completed in accordance with the Contract, except for any minor outstanding work and defects (as listed in the Taking-Over Certificate) which will not substantially affect the safe use of the Works or Section for their intended purpose (either until or whilst this work is completed and these defects are remedied); or

b. reject the application by giving a Notice to the Contractor, with reasons. This Notice shall specify the work required to be done, the defects required to be remedied and/or the documents required to be submitted by the Contractor to enable the Taking-Over Certificate to be issued. The Contractor shall then complete this work, remedy such defects and/or submit such documents before giving a further Notice under this Sub-Clause.

3. If the Engineer or Employer does not issue a Taking-Over Certificate or reject the Contractor's application within the 28-day period, and if certain conditions are fulfilled, the Works or Section shall be deemed to have been completed in accordance with the Contract on the fourteenth day after the Engineer or Employer received the Contractor's Notice of application and the Taking-Over Certificate shall be deemed to have been issued.

The Date of Completion of the Works or Section is therefore either the date stated in the Taking-Over Certificate or the date the Taking-Over Certificate shall be deemed to have been issued.

Turning now to the decision in Mears.

Mears Ltd v Costplan Services (South East) Ltd & Ors

Mears Limited ("Mears"), a provider of student accommodation, entered into an agreement for lease ("AFL") with Plymouth (Notte Street) Ltd ("PNSL") to lease student accommodation. PNSL engaged a builder to construct the accommodation. The AFL provided that if practical completion was not achieved by the relevant date, either party could terminate the AFL. Ultimately, Mears sought to be discharged from its obligations under the AFL.

The AFL provided that:

"6.2 The Landlord shall not make any variations to the Landlord's Works or Building Documents which:

6.2.1 materially affect the size (and a reduction of more than 3% of the size of any distinct area shown upon the Building Documents shall be deemed material), layout or appearance of the Property; or... "

Prior to completion of construction, it became apparent that a number of the rooms in the student accommodation were more than 3% smaller than specified. Mears took issue with this and commenced proceedings seeking declarations regarding the true construction of clause 6.2.1 of the AFL and also in respect of the certification of practical completion.

At first instance, the TCC refused to grant declarations sought by Mears relating to whether the proper construction of clause 6.2.1 meant that a reduction of the size of an area of more than 3% was a material breach and that this meant practical completion could be prevented and the building contract terminated. Mears appealed.

Appeal

The Court of Appeal dismissed the appeal and determined that parties could agree that a breach of a particular clause of a contract amounted to a material or a substantial breach of contract. However, the parties did not do that in this case. The parties agreed that a breach of contract would occur if there was a reduction of more than 3% in relation to the room size. The Court held:

  1. The use of the words "material" and "materially" in the clause did not support Mears' argument that the resulting breach of contract was material.
  2. If the parties had agreed that, it would have amounted to an uncommercial result and meant that any breach of the 3% tolerance, no matter how trivial, would have allowed Mears to determine the agreement.
  3. Clear words would be necessary for such a draconian result and there were no such words in the clause.

The Court also noted that PNSL was not attempting to rely on any breaches to its advantage or gain and the question of whether or not the breaches were material or substantial would be a matter for factual assessment (there were some 56 rooms out of tolerance).

Usefully, Coulson LJ considered the authorities relating to practical completion and summarised the law on practical completion as follows:

"a) Practical completion is easier to recognise than define ... There are no hard and fast rules ...

b) The existence of latent defects cannot prevent practical completion ... In many ways that is self-evident: if the defect is latent, nobody knows about it and it cannot therefore prevent the certified from concluding that practical completion has been achieved.

c) In relation to patent defects, the cases show that there is no difference between an item of work that has yet to be completed (i.e. an outstanding item) and an item of defective work which requires to be remedied. Snagging lists can and will usually identify both types of item without distinction.

d) Although one interpretation of Viscount Dilhorne in Jarvis and Lord Diplock in Kaye suggests that the very existence of patent defect prevents practical completion, that was emphatically not the view of Salmon LJ in Jarvis, and the practical approach developed by Judge Newey in William Press and Emson has been adopted in all the subsequent cases. As noted in Mariner, that can be summarised as a state of affairs in which the works have been completed free from patent defects, other than ones to be ignored as trifling.

e) Whether or not an item is trifling is a matter of fact and degree, to be measured against 'the purpose of allowing the employers to take possession of the works and to use them as intended'(see Salmon LJ in Jarvis). However, this should not be elevated into the proposition that if, say, a house is capable of being inhabited, or a hotel opened for business, the works must be regarded as practically complete, regardless of the nature and extent of the items of work which remain to be completed/remedied. Mariner is a good example of why such an approach is wrong. In consequence, I do not consider that paragraph [187] of the judgment in Bovis Lend Lease, with its emphasis on the employer's ability to take possession, should be regarded (without more) as an accurate statement of the law on practical completion.

f) Other than Ruxley, there is no authority which addresses the interplay between the concept of completion and the irremediable nature of any outstanding item of work. And even Ruxley is of limited use because that issue did not go beyond the first instance decision. But on any view, Ruxley does not support the proposition that the mere fact that the defect was irremediable meant that the works were not practically complete."

Accordingly, in relation to practical completion, the Court of Appeal held:

  1. Parties can agree parameters to guide and control certifiers, but they did not do that here.
  2. Whether a departure from drawings is trifling or otherwise is a matter of fact and degree.
  3. In the absence of any express contractual definition or control, practical completion is, at least in the first instance, a question for the certifier.
  4. The fact that the property is habitable as student accommodation does not, by itself, mean it is practically complete.
  5. The issue of whether or not a breach is remediable is irrelevant to the issue of practical completion. If a defect is regarded as trifling then it cannot prevent practical completion, whether it is capable of economic remedy or not. If the defect is more than trifling, it will prevent practical completion, regardless of whether or not it is capable of remedy.

Mears and the 2017 FIDIC Contracts

Mearswill apply to contracts subject to English law and provide guidance to decision-makers in common law jurisdictions. And whilst the 2017 FIDIC Contracts adopt a slightly different approach, there are principles from Mears which can be applied to their administration. In that regard, Sub-Clause 10.1 of the 2017 FIDIC Contracts provides that the Engineer or Employer shall:

"... within 28 days after receiving the Contractor's Notice, either:

(i) issue the Taking-Over Certificate to the Contractor, stating the date on which the Works or Section were completed in accordance with the Contract, except for any minor outstanding work and defects (as listed in the Taking-Over Certificate) which will not substantially affect the safe use of the Works or Section for their intended purpose (either until or whilst this work is completed and these defects are remedied); or

(ii) reject the application by giving a Notice to the Contractor, with reasons. This Notice shall specify the work required to be done, the defects required to be remedied and/or the documents required to be submitted by the Contractor to enable the Taking-Over Certificate to be issued. The Contractor shall then complete this work, remedy such defects and/or submit such documents before giving a further Notice under this Sub-Clause [emphasis added]."

Disputes over completion dates are frequent in construction projects and it is not difficult to imagine disputes arising over the issue or non-issue of a Taking-Over Certificate. Under the 2017 FIDIC Contracts, and consistent with the decision in Mears, unless there is a contractual provision providing otherwise, then the decision as to whether or not to issue a Taking-Over Certificate is a matter for the Engineer or the Employer in the first instance. If parties are not content with that being the case then parties should agree parameters to guide or control the certifiers. Any such parameters must be reflected in amendments to the contract and in clear terms.

Disputes are likely to arise as to whether or not outstanding work or defects are "minor" and whether or not they "substantially affect" the safe use of the Works or Section for their intended purpose. In Mears, whilst the argument was centred on whether a breach of a clause was material, the parties did agree as to whether a reduction was "material". Similarly, parties may attempt to agree or qualify in the terms of their contracts what constitutes "minor" outstanding work or defects and what "substantially affect" is taken to mean. Again, if parties intend to do this then it must be reflected in amendments to the contract in clear terms. Absent any express contractual qualification, if one applies the decision in Mears, whether or not outstanding work or defects are "minor" would be a matter of fact and degree. As to whether or not the outstanding work or defect would "substantially affect" the safe use of the Works, there is some guidance to be found from Mears. The Court of Appeal made clear that if a defect is trifling it cannot prevent practical completion but if a defect is more than trifling then it will prevent practical completion. Applying that to the 2017 FIDIC Contracts, it may be argued that a defect which is trifling is one which does not substantially affect the safe use of the Works.

Conclusion

As is clear from the above, there are a number of possible scenarios where disputes may arise over the issue of a Taking-Over Certificate. Mears has clarified the principles relating to practical completion and they may impact on those using the 2017 FIDIC Contracts. Parties using them should be aware that any amendments, whether to place controls on certifiers, to clarify what constitutes minor defects, or otherwise, need to be in clear terms which are reflected in the contract. Absent that, then any decision in the first instance will be a matter for the certifier.

International Quarterly is produced quartely by Fenwick Elliott LLP, the leading specialist construction law firm in the UK, working with clients in the building, engineering and energy sectors throughout the world.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Similar Articles
Relevancy Powered by MondaqAI
RHTLaw Taylor Wessing
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
RHTLaw Taylor Wessing
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions