UK: Providing For Concurrent Delay: Contract Provision Trumps Common Law Principle

Last Updated: 17 August 2018
Article by Iain Drummond

In North Midland Building Ltd v Cyden Homes Ltd, the Court of Appeal held that an express contractual term allowing an employer to levy liquidated damages for periods of concurrent delay took precedence over a common law principle known as the prevention principle.

Background

Cyden Homes Limited (CH) employed a contractor, North Midland Building Limited (NMB), to design and build a large house in the Midlands, under a JCT Design and Build construction contract. The contract provided for a completion date of 18 June 2010, with liquidated damages of £5,000 per week being available thereafter for certain delays.

"Concurrent delay" arose in the works, in the sense of a delay which was the fault of CH arising concurrently with a delay which was the fault of NMB. The question for the court was whether this delay entitled NMB to an extension of the contractual completion date.

CH maintained that the contract provided a straightforward answer to this question. Amended clause 2.25.1.3(b) stated that in considering an extension of time, "any delay caused by a Relevant Event which is concurrent with another delay for which the Contractor is responsible shall not be taken into account". Accordingly, CH argued that concurrent delay would not entitle NMB to an extension of time to the completion date.

The prevention principle

NMB conceded that the language of clause 2.25.1.3(b) was clear. However, NMB sought to strike down the clause by reference to a common law doctrine known as the "prevention principle". This is a general contractual principle whereby a party cannot do something that prevents another party performing a contractual obligation and then found on that non-performance. In the context of construction contracts, one application of the prevention principle is that an employer cannot found on a contractor's failure to perform an obligation by a particular date if the employer has prevented that performance.

NMB maintained that since clause 2.25.1.3(b) purported to allow CH to found upon a failure to perform which CH was itself preventing, the prevention principle was engaged and rendered clause 2.25.1.3(b) inoperable. This was not on the basis that the prevention principle was an implied term (since an implied term cannot take precedence over an unambiguous express term), but rather because it amounts to an overriding legal policy principle akin to the rule that the courts will strike down penalty clauses. The result, NMB argued, was that it was entitled to an extension of time for the concurrent delay and CH was not entitled to levy liquidated damages for the delay period.

The Court of Appeal rejected this argument. Clause 2.25.1.3(b) was unambiguous. The court rejected the proposition that the prevention principle is analogous to the rule against penalty clauses and concluded that the prevention principle cannot override an unambiguous clause agreed between the parties. In any case, the court took the view that the prevention principle "has no obvious connection with the separate issues that may arise from concurrent delay." Therefore, even if the court had concluded that the prevention principle amounted to an overriding rule of legal policy, it would not have displaced clause 2.25.1.3(b).

Liquidated damages

NMB's alternative argument was that even if clause 2.25.1.3(b) was valid, there was an implied contractual term which prevented CH from recovering liquidated damages in relation to any period of concurrent delay. NMB maintained that "it would be bizarre if [CH] could recover liquidated damages for a period of delay for which it was responsible."

The court rejected this argument too, concluding that the extension of time provisions were "inextricably linked to the provisions relating to liquidated damages". This was so because the "primary purpose of an extension of time provision is to give the contractor relief against the levying of liquidated damages for delays which were not his responsibility under the contract". Given that the contract ruled out an extension of time where there was concurrent delay, it followed logically that liquidated damages could be levied in respect of such periods.

Conclusion

Finally, the court pointed out that in cases of concurrent delay, both the employer and contractor can equally argue that it would be unfair for the other to be able to benefit from delay which it is partly responsible for. The extension of time provisions found in the JCT suite of contracts have been held by the courts to benefit the contractor in cases of concurrent delay – in other words, the contractor is entitled to an extension of time notwithstanding that it was partly to blame for the delay. By contrast, clause 2.25.1.3(b) as agreed by the parties in this case benefited the employer by disallowing an extension of time to the contractor despite the fact the employer was partly at fault for preventing the contractor's timely performance.

The court noted that "Either result may be regarded as harsh on the other party; neither could be said to be uncommercial or unworkable." This case therefore demonstrates that while it may not be possible to reach an outcome in such cases which is wholly fair to both parties, it is at least possible to achieve commercial certainty by agreeing the position clearly in advance.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions