UK: Changes To The FIDIC Form Of Contract

Last Updated: 9 January 2017
Article by Jeremy Glover

At the International Contract Users Conference held in London on 6—7 December 2016, FIDIC finally unveiled its proposed revisions to the 1999 Rainbow Suite.  More specifically, FIDIC issued a pre-release version of the Yellow Book, the Contract for Plant & Design Build. The contract was said to be "for viewing only".

FIDIC said that the Yellow Book second edition would be formally published by them during 2017. The date of that release is not yet known. FIDIC also said that they intended to issue second editions of all three contracts that form part of the original 1999 Rainbow Suite, namely the Red, Yellow and Silver Books, together in 2017.

Whilst it is our intention to provide a special FIDIC issue of IQ early in 2017, which will examine the proposed changes in more detail, we thought it might be helpful as a starting point to provide a summary of the key themes and issues arising out of the new draft contract.

Why are the Contracts being Amended?

FIDIC have explained that the underlying philosophy behind the update is as follows:

  • To enhance project management tools and mechanisms;
  • To reinforce the role of the Engineer;
  • To achieve a balanced risk allocation.  This is being achieved through more reciprocity between the Parties;
  • To achieve clarity, transparency and certainty;
  • To reflect current international best practice;
  • To  address issues raised by users over the past 17 years arising out of use of the 1999 Suite; and
  • To incorporate most recent development in FIDIC contracts, in particular the Gold Book.

This is why a key theme of the revised Yellow Book is the increased emphasis on dispute avoidance.

Dispute Avoidance

FIDIC is seeking to promote dispute avoidance in a number of ways:

(a) Splitting Clause 20

As FIDIC had made clear during 2016, they have split clause 20 in two.

The reason for this is to try and make clear that making a Claim is not the same as a Dispute. To put forward a Claim is to make a request for an entitlement under the Contract. A Dispute arises if that Claim is rejected (in whole or in part) or ignored.

  • Clause 20 is now entitled:
    "Employer's and Contractor's Claims"
  • Clause 21 is now entitled:
    "Disputes and Arbitration"

(b) Changes to the role of the Engineer

The Engineer will continue to have a pivotal role in administration of the project. Clause 3 now has eight sub-clauses. Indeed it is a feature of the new Yellow Book that it is longer than its predecessor. FIDIC said at the London Conference that the word count had increased by approximately 50%.  The reason for this was to achieve a contract that was more structured, with clear processes and procedures.  If this can be achieved, then the contract as a whole can be better understood by everyone.

Under the new Yellow Book:

  • The Engineer shall continue to be deemed to act for the Employer, save that new sub-clause 3.2 says that the Engineer is not required to obtain the Employer's consent before making a Determination under new sub-clause 3.7.
  • There is a new role for an "Engineer's Representative" – who is based on site for the whole time of the Project.
  • New sub-clause 3.7 is headed "Agreement or Determination" which reflects the fact that the Engineer is under a positive obligation to encourage agreement of claims. The Engineer must also provide the Parties with a record of any consultation that takes place when trying to reach such agreement.
  • If the Engineer fails to make a Determination within the stated time limits, then they are deemed to have rejected the claim.  This means that it can be referred to the Dispute Avoidance Board.
  • When acting to seek to reach an Agreement or to make a Determination under new sub-cause 3.7, the Engineer is said not to be acting for the Employer but to be acting "neutrally" between the Parties.

The word "neutrally" is new, though it is not defined.  It is not an easy word to define and it was the subject of much discussion at the London Conference. FIDIC said that in choosing the word, it did not mean "independent" or "impartial".  A better interpretation might be "non-partisan" and the word "neutral" has been chosen to make it clear that when making a Determination the Engineer is not, as noted above, acting on behalf of the Employer.  This is something which will undoubtedly be the subject of much further debate.

(c) Dispute Adjudication/Avoidance Boards ("DABs")

The change in name alone is a clear reference to the new role of DABs. In new clause 21, all DABs will be standing DABs, although the Guidance Notes will include an option for the use of an ad hoc DAB, as and when a dispute arises. The primary purpose of Dispute Boards, preventing claims from becoming disputes, is easier to achieve if there is a standing board which can act as a sounding board to guide the project.

The DAB rules are not currently included as part of the revised Yellow Book. We understand that although FIDIC did give serious consideration to adopting the updated ICC Dispute Board Rules, they have decided to retain the FIDIC DAB Rules. Again, these are likely to follow the Rules to be found in the FIDIC Gold Book, albeit with added focus on dispute avoidance.

By new sub-clause 20.3, the Parties may if they so agree: 

"jointly refer a matter to the DAB in writing (with a copy to the Engineer) with a request to provide assistance and/or informally discuss and attempt to resolve any issue or disagreement that may have arisen between them during the performance of the Contract".

The DAB also has the power to invite the Parties to make such a referral if it becomes aware of any such issue or disagreement. This positive obligation might become a very useful dispute avoidance tool indeed.

(d) Early warning

Another feature of dispute avoidance is the concept of advance warning, giving early notice of a potential problem. By encouraging the Parties to do this, it is hoped that they can then work together to resolve the potential difficulty at an early stage when it is relatively minor and thereby prevent it from escalating into something altogether more serious.

The new sub-clause 8.4 follows the Gold Book, by providing that each Party (and the Engineer) shall endeavour to advise the other Party in advance of any known or probable future events or circumstances which may adversely affect the work.

The Claims Procedure and the FIDIC Time Bar

The FIDIC Form currently requires both the Employer and Contractor to submit claims. This has continued as part of new clause 20 which is clearly headed "Employer's and Contractor's Claims".  This closer alignment of Parties' claims is a key part of FIDIC's attempts to achieve balance and reciprocity between the Parties.

FIDIC's intention is that if there is a clearly defined process, then that can help maintain relationships as both Parties will know exactly where they stand and why the other is taking the steps they are to submit their claim. That said, new clause 20.2, which sets out the claims process, is one of the longest clauses in the Contract and sets out a detailed procedure.  We will analyse this in detail in our 2017 IQ FIDIC Review, but the length of the new sub-clause is a signal that the process may not be a simple and straightforward one to follow.

This will undoubtedly place an increased burden on both the Employer and Contractor to follow these new administrative requirements. This is especially the case as the 28-day time bar has been retained. In fact, as a whole, there are more specified time limits within the revised Contract, the failure to follow which will lead to sanctions. As a result this may actually lead to an increased number of claims, as both Parties will need to try and ensure that they do not lose the right to make a claim.

This was certainly the view of the London Conference. Together with Nicholas Gould we led a session entitled "Managing Claims and Avoiding Disputes".  As part of that session we asked the audience for their views on the likely impact of the revisions to the number of claims in the new Yellow Book. Their reply was revealing:

  • Less claims?                         24%
  • No change?                          26%
  • More claims?                        50%

Of course more claims do not necessarily mean more disputes, one reason no doubt for the increased emphasis on dispute avoidance.

Notices

FIDIC have made it clear that a notice given under the new contract must clearly state that it is a notice and make reference to the sub-clause under which it is issued.   This is to try and reduce disputes about what is a notice where Parties try and argue that references in a programme or progress report actually constitute notice of a claim.

That said, new sub-clause 20.3 does provide the DAB with the power to waive a failure to follow a time bar requirement, albeit there is a 14-day time limit on a party seeking relief for the refusal of an Engineer to consider a claim because it is said to be time barred.

The DAB can take the following into account:

  • Whether the other Party would be prejudiced by acceptance of the late submission;
  • Whether the other Party had prior knowledge of the event in question or basis of claim; and
  • The extent to which, if at all, the Engineer may already have proceeded to make a determination, or more likely sought to negotiate an agreement.

The Programme and Extension of Time Claims

In keeping with the trend in international contracts, and in line with the Red Book subcontract, there are increased programming obligations (16 are listed) within new sub-clause 8.3.

Although FIDIC have retained their position that the programme does not become a contract document, the Engineer is required to review the programme and say if it does not comply with the contract. If the Engineer does not do this within 21 days, then the programme is deemed to comply.

There is also a positive obligation on the Contractor to update the programme whenever it ceases to reflect actual progress.

There is an interesting reference to concurrent delay, with new sub-clause 8.5 saying that if a delay caused by the Employer is concurrent with a Contractor delay, then the entitlement to an extension of time shall be assessed:

 "in accordance with the rules and procedures stated in the Particular Conditions".  

This rather neutral comment will of course have the effect of raising the issue of concurrency as a matter that needs to be dealt with by the Parties when they negotiate and finalise the contract.

BIM

There is no specific mention of BIM. It is perhaps the case that the adoption and use of BIM is something that is more likely to be dealt with in either the Particular Conditions or as additional contract documents, through, for example, the adoption of a BIM Protocol and Execution plan.

Force majeure and Exceptional Risks

As was flagged in advance, here FIDIC has followed the Gold Book which is considered to represent a more collaborative, risk-sharing approach than the 1999 suite of contracts. The new Yellow Book does not follow the 1999 clause 19 force majeure provisions. Instead, it drops clause 19 completely in favour of a new clause 18 that is headed "Exceptional Risks", and clause 17 (which was formerly risk and responsibility) has been renamed "Risk Allocation". The definition of exceptional risks is very similar to the force majeure definition previously to be found in clause 19.

However, new clause 17 is rather different, setting out the risks that the Employer and Contractor are to bear in a very detailed manner, with the Contractor being entitled to an extension of time and its costs if there are any exceptional risks or Employer risks during the design/build period.

Conclusions

It is, of course, too early to make any definitive conclusions on the new revisions.  The devil, as they say, is in the detail. However, the increased emphasis on dispute avoidance, which as we have said is perhaps the most striking change within the revised contract, is to be welcomed.

Will the contract change again before it is issued in final form for use?  A good question: the impression we gleaned from the London Conference was that the intention of FIDIC was certainly not to make any major changes, but we shall see.

This is just a short summary of some of the most important features of the new Yellow Book.  Look out for our more detailed review in the first IQ of 2017.


International Quarterly is produced quartely by Fenwick Elliott LLP, the leading specialist construction law firm in the UK, working with clients in the building, engineering and energy sectors throughout the world.


The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Jeremy Glover
Similar Articles
Relevancy Powered by MondaqAI
Fenwick Elliott LLP
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Fenwick Elliott LLP
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions