UK: The SCL Protocol: Time For Change?

Last Updated: 4 December 2015
Article by Jeremy Glover

The Society of Construction Law's (SCL) Delay and Disruption Protocol1 was first published in 2002. It provides, in short, a scheme whereby delay may be much better controlled and managed during the construction process. The SCL says that overall, the Protocol aims to set out good practice (rather than best practice). Although the Protocol has no force of law (unless it is adopted into a contract) what it does provide is a previously absent consensus of expertise as to what is sound and what is unsound in the area of delay analysis.

The stated aim of the Protocol is that: "in time, most contracts will adopt the Protocol's guidance as the best way to deal with delay and disruption issues". Despite this, it is probably fair to say that whilst its suggestions are frequently adopted in debate about the best or right way to record and present delay, the Protocol has not been widely adopted or implemented by way of contract drafting and contract procedure. This may be one reason why the Protocol is currently being revised.

The origins of the review can be found in a SCL meeting held in April 2013, chaired by Lord Justice Jackson, to mark the 10th anniversary of the Protocol. The consensus at that meeting was that it was time for a review of the Protocol and the SCL set up a committee to do just that.

The SCL has noted that the review was held against a background of:

(i)   developments in the law and construction industry practices since 2002;

(ii)  feedback on the uptake of the Protocol since that time;

(iii) developments in technology since 2002;

(iv) an increase in the scale of large projects, leading to a wider divergence between small-scale and large-scale projects;

(v)  anecdotal evidence that the Protocol is being used for international projects as well as domestic UK projects.

There were eight specific terms of reference:

(i)    whether the expressed preference should remain for time impact analysis as a programming methodology where the effects of delay events are known;

(ii)   the menu and descriptions of delay methodologies for after the event analysis;

(iii)  whether the Protocol should identify case law (UK and international) that has referenced the Protocol;

(iv)  record keeping;

(v)   global claims and concurrent delay;

(vi)  approach to consideration of claims (prolongation/disruption – time and money) during currency of project;

(vii) model clauses; and

(viii) disruption.

On 1 July 2015, the SCL issued the first fruits of the review, Rider 1, which covers the first two items set out above.

What has not changed?

The original approach of the Protocol was that extensions of time should be dealt with at or soon after the time of the delaying event, so that the parties know where they stand. The prevailing rationale was that having clarity was of greater value for all parties than a wait and see approach. This approach has been maintained. The authors of Rider 1 say this:

"the contemporaneous submission and assessment of EOT claims2 is elevated to a core principle. This allows appropriate mitigation measures to be considered by the project participants so as to limit the impact of the delay event. It also provides the Employer and the Contractor with clarity around the completion date so that they can understand their risks and obligations and act accordingly. These objectives cannot be met if the Contractor does not submit timely notices, particulars and appropriate substantiation for its EOT claims, or if the CA does not assess those claims contemporaneously. These are key issues for minimising time related disputes."

This is undoubtedly a sensible starting point from the point of view of good commercial practice. It does mean that extensions would have to be granted, not on the test of what actually caused delay, but on the test of what looked likely to cause delay at the time of the delaying event. This can sometimes mean that:

(i)   delay is inevitably to be analysed on a "first cause" basis, not an "ultimately critical" basis;

(ii)  the programme in currency at the time of the delaying event will take precedence over the actuality; and

(iii) any subsequent forensic examination of what extensions of time ought to have been granted should properly look at, not what actually happened, but the much more subjective question of what the parties ought to have expected would happen.

What has changed?

The original Protocol recommended that one particular form of delay analysis, namely the time-impact form of delay analysis methodology, be used wherever the circumstances permitted "both for prospective and (where the necessary information is available) retrospective delay analysis". The time-impact form of analysis involves introducing delay events into the most contemporaneous programme and then updating the programme by impacting onto it the assumed effect of the delay event in question. By doing this, you take account of the status of the works at the time and then introduce the delay event into the programme and establish the likely effect or impact on the completion date.

This was not universally supported and was one of the main reasons why the meeting in 2013 had pressed for a review. One particular issue with the time-impact analysis can be its reliance upon theoretical modelling and not the actual sequence of events. This was recognised by the Review Committee who noted in Rider 1 that "there was a strong argument" put forward that contemporaneously submitting and assessing an EOT application and awarding an EOT on a prospective basis (i.e. the use of a time-impact analysis):

"can sometimes lead to unrealistic results if it subsequently transpires that the EOT claimed is significantly more than the delay attributable to the Employer Risk Event".

At the same time, the original Protocol made no mention of the "windows" form of delay analysis which, over the past 10 years, has certainly become one of the most used forms of delay analysis, arguably because it is considered to be one of the most reliable.

Whilst Rider 1 still favours the time-impact approach, where there is a prompt evaluation of the delay during the project. Now, no one form of delay analysis is preferred, where that analysis is carried out some time after the delay event or its effect. Instead Rider 1 sets out the factors that need to be taken into account in selecting the most appropriate form of delay analysis as well as providing a helpful explanation of many of the delay analysis methodologies currently in common use.

Further, Rider 1 recognises that crucial factors in determining the most appropriate methodology (namely, the Contract terms, the circumstances of the project, nature of the relevant or causative events, the claim or dispute, the value of the project, the time available and the available project records) will vary between projects. As Rider 1 notes:

"fundamentally the conclusions of the delay analysis must be sound from a common sense perspective in light of the facts that actually transpired on the project. This is because a theoretical delay analysis which is divorced from the facts and common sense is unhelpful in ascertaining whether in fact the relevant delay event caused critical delay to the completion date and the amount of that delay."

This application of sound common sense is encouraging. Indeed, it is backed up by noting that critical path analysis is not necessarily limited to the use of specialist programming software. Rider 1 notes that such software can be "a powerful analytical tool" but also reminds those preparing an extension of time claim that sometimes the critical path to completion can be more reliably established through a:

"practical analysis of the relevant facts or by analysis of production and/or resource data".

A view from the TCC

This is an approach which has been endorsed by the English courts.

For example Mr Justice Akenhead, in 2012 in the case of Walter Lilly v Giles Patrick MacKay,3 carried out a comprehensive review of the authorities and provided guidance on a number of important issues including the correct approach for a court of tribunal in calculating extensions of time. Indeed, the Judge noted that the approach of both experts:

"involved in reality doing the exercise that the Court must do which is essentially a factual analysis as to what probably delayed the Works overall".

Mr Justice Akenhead's view can be summarised as follows:

(i)   It is first necessary to consider what the contract between the parties requires in relation to the fixing of an appropriate extension of time.

(ii)  Whilst the architect prior to the actual practical completion can grant a prospective extension of time, which is effectively a best assessment of what the likely future delay will be as a result of the relevant events in question, a court or arbitrator has the advantage, when reviewing what extensions were due, of knowing what actually happened.

(iii) The court or arbitrator must decide on a balance of probabilities what delay has actually been caused by such relevant events as have been found to exist. How the court or arbitrator makes that decision must be based on the evidence, both actual and expert.

(iv) The extension must relate to the extent to which "completion of the works is likely to be delayed" by the relevant event or events.

(v)  Mr Justice Akenhead endorsed the view of Mr Justice Colman in the Chestermount case, where he said: "Fundamental to this exercise is an assessment of whether the relevant event occurring during a period of culpable delay has caused delay to the completion of the Works and, if so, how much delay."

(vi) In the context of this contractual-based approach to extensions of time, one cannot therefore carry out a purely retrospective exercise. What one cannot do is to identify the last of a number of events which delayed completion and then say that it was that last event at the end which caused the overall delay to the works.

(vii) In the assessment of what events caused what overall or critical delay, one needs also to bear in mind that it is not necessarily the item or area of work that is finished last which causes delay. It is what delays that final operation, which in itself takes no longer than it was always going to take, that must be assessed.

(viii) If there is an excessive amount of snagging and therefore more time has to be expended than would otherwise have been reasonably necessary to perform the de-snagging exercise, it can potentially be a cause of delay in itself.

(ix) The court should be very cautious about giving significant weight to the supposedly contemporaneous views of persons who did not give evidence.

Mr Justice Akenhead's judgement also referred to concurrency which he thought only come into play where at least one of the causes of delay is a relevant event and the other is not. It will be interesting to see the extent to which the next stage of the review agrees with his conclusions that where delay is caused by two or more effective causes, one of which entitles the contractor to an extension of time, the contractor is entitled to a full extension not a reasonably apportioned part of the concurrently caused delay.

The approach to notices

We have written elsewhere in this Review about the importance of complying with project notice procedures and time bars. This is, unsurprisingly, endorsed by Rider 1 which stresses that:

"The parties and the CA should comply with the contractual procedural requirements relating to notices, particulars, substantiation and assessment in relation to delay events. Applications for EOT should be made and dealt with as close in time as possible to the delay event that gives rise to the application."

Conclusion

The review on the remaining six issues is ongoing and it is understood that a draft second edition of the Protocol, which will incorporate Rider 1, will be available for consultation towards the end of 2015.

Rider 1 notes that the expressed aim of the second edition of the Protocol will be to provide :

"Practical and principled guidance on proportionate measures that can be applied in relation to all projects, regardless of complexity or scale, to avoid disputes and, where disputes are unavoidable, to limit the costs of those disputes".

This is a wholly laudable aim, and it is to be hoped that the final second edition builds on the common sense approach adopted in Rider 1 as it seeks to achieve this. Whether or not that will lead parties to expressly incorporate the revised Protocol into their contracts remains to be seen.

Footnotes:
1. Further details can be found on the SCL website: www.scl.org.uk
2. As Rider 1 also notes, when it comes to financial losses the opposite approach is considered to be usually correct, with compensation being usually awarded only from a retrospective perspective, based on the actual costs incurred.
3. [2012] EWHC 1773 (TCC).

This article is taken from Fenwick Elliott's 2015/2016 Annual Review. TO read further articles go to www.fenwickelliott.com/research-insight/annual-review/2015

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Jeremy Glover
Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions