UK: Delayed Delivery: The Right To Cancel Shipbuilding Contracts

Last Updated: 13 February 2015
Article by Wai Yue Loh and Ajay Ahluwalia

Zhoushan Jinhaiwan Shipyard v. Golden Exquisite Inc. [2014] EWHC 4050 (Comm)

A recent decision in the Commercial Court offers helpful guidance to both shipyards and buyers facing and considering possible cancellations of shipbuilding contracts due to delayed delivery.

The background facts

The Court heard appeals from four arbitration awards in relation to disputes regarding the interpretation of four shipbuilding contracts between a Chinese shipyard (the "Yard") and four buyers ("Buyers", all part of the same group). The contracts were materially identical and, in each case, the Buyers relied on a contractual right to cancel the contract for delayed delivery of the vessel.

In arbitration, the Tribunals found that the Buyers' cancellations were valid. The issue on appeal was whether the Buyers had lawfully cancelled the contracts, or whether, as the Yard alleged, cancellation was unlawful because the Buyers had themselves caused part of the delays to the delivery of the vessels.

Right to cancel

The contracts provided the Buyers with the right to cancel the contracts in the following circumstances:

  • Under Article III.1(c): after 210 days of "non-permissible delays" to the contractual delivery date; and
  • Under Article VIII.3:
    1. after 225 days of "permissible delays", which were specific causes beyond the Yard's control and which were enumerated in Art VIII.1; and
    2. after 270 days of combined "permissible" and "non-permissible" delays.

The Buyers gave notice of cancellation of the contracts more than 270 days after the contractual delivery date, and claimed a refund of the instalments paid. If, as the Buyers claimed, the contracts were cancelled under Article III.1(c), the Yard would also have to pay interest. There would be no obligation to pay interest if the contracts were cancelled under Article VIII.3.

After the Buyers gave notice of cancellation, the Yard alleged that the Buyers were in breach of Article IV of the contracts, which provided for inspection of the vessel by a supervisor appointed by the Buyers. Although the Yard had not previously issued any notice of such delays under the contracts, the Yard alleged that the Buyers were in breach of their obligation to "..carry out inspections in accordance with the agreed inspection procedure and schedule and usual shipbuilding practice...". The Yard alleged that the Buyers' supervisors had worked insufficient hours, imposed extra-contractual requirements and taken unreasonable amounts of time to return crucial documentation.

The Yard therefore sought a finding that on a true construction of the contracts, the delays caused by these so-called "Buyers' breach delays" of at least 90-100 days' each should not count towards the delay thresholds relied upon by the Buyers. If the days lost to "Buyers' breach delays" did not count towards the thresholds, the Buyers' cancellation of the contracts was premature and unlawful.

If the Yard was correct that the cancellations were unlawful, the Buyers would have been in repudiatory breach of the contracts, and the Yard would have been entitled to keep the instalments paid and re-sell the vessels, crediting the Buyers only with the balance of the proceeds of sale after the Yard had recouped its expenses.

The Commercial Court decision: types of delay

The Court rejected the Yard's arguments and found in favour of the Buyers. The Court found that there were only three types of delay provided for in the contractual scheme:

  1. Permissible delays: delays defined in Article VIII.1 and deemed to be outside the control of the Yard. They allowed the Yard an extension of time for delivery of the vessel and, if they persisted, gave the Buyers a right to cancel the contracts and recover the instalments (without interest).
  2. Non-permissible delays: delays which did not allow the Yard any extension of time for delivery but which, if they persisted, allowed the Buyers to cancel the contracts and recover the instalments of the price paid with interest.
  3. Excluded delays: delays excluded from consideration when determining whether the Buyers were entitled to reduce the contract price or cancel the contract because of delayed delivery, but which delays may, under the terms of the contract, have allowed the Yard an extension of time for delivery of the vessel.

The Court rejected the Yard's argument that the "Buyers' breach delays" constituted a separate, fourth category of delays.

The Court found that the wording of Article IV did not contain any provision that permitted the time for delivery to be extended because, as a matter of contractual interpretation, the Buyers' supervisor had no power to delay the construction of the vessel: in fact, the Yard was not required to wait for the Buyers' supervisor to attend tests and carry out inspections. "Buyers' breach delays" were not, therefore, excluded delays.

"Buyers' breach delays" also did not fall within the scope of Article VIII.1, and so were not permissible delays, and did not allow the Yard an extension of time for delivery. Even if "Buyers' breach delays" were permissible delays, the Yard's failure to comply with the contractual requirement to give notice meant that the Yard could not rely on these delays to claim an extension of time for delivery. The delays were therefore non-permissible delays that did not allow the Yard an extension of time for delivery.

At the time of the notices of cancellation, the Buyers had the right to cancel the contracts under both Article III.1(c) and Article VIII.3. The Buyers were entitled to cancel the contract under Article III.1(c), obtain a refund of paid instalments and claim interest at the rate of 5% per annum.


The decision presents valuable assistance to parties considering or facing possible cancellations under shipbuilding contracts. Parties should be wary of stretching the meaning of the contractual terms: the Court described the Yard's arguments as "untenable" and cautioned against an over-reliance on "commercial common sense" to justify interpretations that were "inconsistent with the language of the contract".

As a practical tip, parties with genuine concerns over issues causing delays to the construction of the vessel should issue notices of delay under the contract to ensure they are not precluded from relying on such delays at a later stage.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

In association with
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.


Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.


Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.


A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.


This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.


If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.


This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at and we will use commercially reasonable efforts to determine and correct the problem promptly.