UK: CPC 2013 - The New CIOB Contract For Use On Complex Projects

Last Updated: 1 November 2013
Article by Jeremy Glover

In April 2013, the Chartered Institute of Building (CIOB) published a contract for use with complex projects (known as the Complex Projects Contract or CPC 2013). Speaking about the contract, one of its authors, Keith Pickavance, boldly said:

"This is a modern day contract designed for the data age. It underlines and meets the need for a collaborative and competent approach to how risks are managed utilising transparent systems of data. It can be used with, or without, Building Information Modelling and has been drafted to work in any country and legal jurisdiction around the world."

The CPC 2013 comes in four parts:

(i) Contract agreement or articles of agreement. These can be freely downloaded from the CIOB website – www.ciob.org.uk.

(ii) Conditions of contract which, as you would expect, contain the terms and conditions for carrying out the works, subject to any amendment introduced by a special condition.

(iii) Seven appendices:

  • Appendix A - Definitions;
  • Appendix B - Contract data;
  • Appendix C - Building information modelling – the contract claims to be the first (UK) K form of contract which is compliant with the recommendations of the UK BIM Task Force for use on Level 2 BIM projects;
  • Appendix D - Working schedule and planning method statement;
  • Appendix E - Progress records;
  • Appendix F - Events; and
  • Appendix G - Issue resolution.

(iv) User notes.

What is a complex project?

A good question. The CPC 2013 has been written for use on complex projects, in the UK or overseas - therefore potentially the Middle East. The Guide refers to a complex project as one which "cannot be effectively managed intuitively" and which has one or more of the following features:

  • work involving complex mechanical, electrical or plumbing services;
  • more than one structure;
  • a structure more than 15m (or 50 feet) high;
  • useable space below ground;
  • a construction period in excess of 1 year;
  • design continuing during the construction period;
  • multiple main contractors;
  • more than 20 subcontractors;
  • multiple possession and/or access dates; and/or
  • multiple key dates or sectional completion dates.

Dispute (and Issue) Resolution

One of the features of the CPC 2013 is its approach to dispute resolution. The contract notes, at clause 66.1, that the parties may settle any dispute by mediation. Whilst this is always the case, the fact that it is specifically mentioned in the contract can be seen as useful, as it suggests that mediation is a part of the contract set-up. The contract also provides for adjudication and arbitration. However there are two features of note:

(i) Unless the parties agree otherwise, any adjudicator's decision or arbitral award is to be a public document.

(ii) No dispute can be referred to adjudication unless and until the Principal Expert has made a Determination in accordance with clause 65 of the contract: Issue Determination.

In many respects, Issue Determination appears to be intended to operate like a mini-DAB or adjudication process. The idea is to try and deal with issues immediately, whenever a difference of opinion arises. As a first step, the parties are required to meet to try and resolve the issue; if that is unsuccessful, then the Principal Expert is brought in to issue a Determination within 20 business days. According to Appendix G, the purpose of Issue Resolution is to assist the parties in the management of risks and reduce the possibility of formal proceedings, which means that the expert is given wider powers than might be expected:

"the Principal Expert must issue its Determination on the basis of its own investigations and shall not be limited by the submissions of the parties."

It remains to be seen just how disputes, if they arise, are resolved, as the timescales, once the formal Issue Resolution process commences, are very tight; contrast the CPC's 20 business days with the 84 days allowed by FIDIC.

Communications

The CPC 2013 is very much a creature of the electronic age. To this end, all documentation and site information must be "published" either by preparing the submittal into a Common Data Environment to which everyone has access, or by electronic transfer or email. The reason for this is said to be the need to encourage "transparency in the submittal of information requirement for the management of risk". For example, the Working Schedule or Contractor's critical path network is expected to be handed over in a native file format, not simply in hard copy on paper.

Collaboration

Clause 5.1 has a familiar ring to those acquainted with the NEC3:

"The parties shall work together in the manner set out in the Contract and shall co-operate in a spirit of mutual trust and fairness."

The importance of the first part of that sentence should not be ignored. Those of you who have read our articles on Good Faith in Issues 5 and 6 of IQ will know that the English courts take a restrictive view on similar obligations. "What good faith requires is sensitive to context." LJ Beatson in the case of Mid-Essex Hospital Services NHS Trust v Compass Group UK and Ireland Ltd1suggested that one should take a narrow interpretation of any clause that suggests that (in English law at least) parties must exercise the duty of good faith. He said:

"In a situation where a contract makes such specific provision, in my judgment care must be taken not to construe a general and potentially open-ended obligation such as an obligation to 'co-operate' or 'to act in good faith' as covering the same ground as other, more specific, provisions, lest it cut across those more specific provisions and any limitations in them."

Time management

It is clear that to the CIOB, this is a key attraction of the CPC 2013. The CIOB on its website describes the CPC 2013 as being the "world's first time management contract for complex projects". The CPC 2013 focuses on managing time to ensure projects are delivered to specification on budget and without delays. The CIOB contrasts other contracts which it says "target failure" and "through persuasion" target "financial compensation for failure". The CIOB says that the CPC 2013 provides the procedures to enable parties to manage time (and cost) risk events in a modern and proactive fashion. How does the contract do this?

One way is through the appointment of a Project Time Manager ("PTM"). The role of the PTM is to advise the Contract Administrator on project time-related issues. This will include analysing the effect of any potential delay events that arise. It is noticeable that such an assessment is not made on the traditional "fair and reasonable" basis, but on the Contractor demonstrating the additional time needed as a consequence of the "event". The PTM is paid by the Employer but, by clause 5.2 of the contract, is to act "independently and fairly". The Guidance Notes say that the PTM is "responsible for ensuring that the Contractor's time management processes are satisfactory" and must:

"check on a regular basis, whatever is produced by the Contractor by way of time related information and to accept it, if satisfactory, or reject it, or accept it subject to conditions..."

There is another role under the contract with similar responsibilities, that of the Auditor. The Auditor is to act as the Time Management Expert, and so may have a role in deciding Issue Resolution. The Auditor must, before work commences and at regular intervals, examine the Contractor's Planning Method Statement, Working Schedule and Progress Records. The purpose of the Audit is to ensure that the Constructor's documents comply with the requirements of the contract and the CIOB's Guide to Good Practice in the Management of Time in Complex Projects.2

This focus on detailed record keeping, as well as the careful monitoring of progress and the way in which progress is being recorded through programmes, is a key part of the approach of this new contract. Indeed, the obligations on the Contractor to produce, maintain and regularly update a Working Schedule and Planning Method Statement are set out in some detail at clauses 26 to 34 and Appendix D of the contract.

Conclusion

When a new contract is launched, it is always difficult to tell just how popular it will prove to be. Often, its take-up depends on whether or not it is able to demonstrate its early adoption on a high-profile project, but certainly the CPC 2013, although long (66 clauses), is written in plain English which helps. However, the answer to whether or not the apparent additional administrative burden (particularly on the Contractor) the CPC 2013 seems to impose is worthwhile, will only be answered once the contract is used and the benefits (or not) of that administrative burden (i.e. reduced delay and costs) are demonstrated. That said, at the very least its focus on time management will act as a stimulus for debate.

Footnotes

1. [2013] EWCA 200 Civ

2. www.ciobstore.com/Product.asp?PID=6237

International Quarterly is produced quartely by Fenwick Elliott LLP, the leading specialist construction law firm in the UK, working with clients in the building, engineering and energy sectors throughout the world.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Jeremy Glover
 
In association with
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Check to state you have read and
agree to our Terms and Conditions

Terms & Conditions and Privacy Statement

Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

Use of www.mondaq.com

You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

Disclaimer

Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

Registration

Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.

Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

If you do not want us to provide your name and email address you may opt out by clicking here .

If you do not wish to receive any future announcements of products and services offered by Mondaq by clicking here .

Information Collection and Use

We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

Mondaq News Alerts

In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

Cookies

A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

Log Files

We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

Links

This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

Surveys & Contests

From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

Mail-A-Friend

If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

Security

This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

Correcting/Updating Personal Information

If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

Notification of Changes

If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

How to contact Mondaq

You can contact us with comments or queries at enquiries@mondaq.com.

If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.