India: Can An Arbitrator Award Escalation Charges In The Absence Of Any Clause For Escalation In The Contract?

Last Updated: 1 November 2018
Article by Parth Rawal

In a commercial contract, a tender is procured upon estimation of prices of material and labor to be incurred in future. However, these prices are susceptible to change due to reasons beyond the control of either party. Such unforeseen change in prices, which may shake the very foundation of the bargain, which parties entered into, may lead to frustration of contract, which in turn leads to termination of contract. To avoid such a situation, an escalation clause is added into the contract, which takes into account any future changes in prices of labor and material.

It is a cardinal principle of arbitration, that the arbitrator derives his authority from the terms of the contract and an award passed in contravention of such terms of contract is without jurisdiction and is liable to be set aside. However, there are several instances where contract does not provide for escalation clause and the contract is extended beyond completion period because of no fault of contractor. Thus, contractor suffers losses because of extension of contract and becomes entitled to damages, which include escalation in cost of material and labor. In such a situation, the question that crops up is whether arbitrator can award escalation in cost of material and labor in absence of any clause for escalation in the contract. In a recent case of Union of India (UOI) vs. Varindera Constructions Ltd. and Ors.,1 the Supreme Court, in a special leave petition overturned the decision of division bench, Single Judge and arbitral tribunal and held that in presence of a clause expressly prohibiting escalation charges, arbitrator cannot award escalation charges. However, since there are many aspects of interpretation of escalation charges in varying circumstances, the author in this article expounds upon other situations dealing with interpretation of escalation charges in contract.

Where there is absence of escalation clause in contract

In absence of an escalation clause in contract, the arbitrator is within his jurisdiction to award escalation charges if the delay is not attributable to the contractor himself. This was dealt by Supreme Court in case of Food Corporation of India vs. A.M. Ahmed and Co. and Ors.2 It was held in this case:

"Escalation, in our view, is normal and routine incident arising out of gap of time in this inflationary age in performing any contract of any type. In this case, the arbitrator has found that there was escalation by way of statutory wage revision and, therefore, he came to the conclusion that it was reasonable to allow escalation under the claim. Once it was found that the arbitrator had jurisdiction to find that there was delay in execution of the contract due to the conduct of the FCI, the Corporation was liable for the consequences of the delay, namely, increase in statutory wages. Therefore, the arbitrator, in our opinion, had jurisdiction to go into this question." This has been reiterated by court in case of Assam State Electricity Board and Ors. vs. Buildworth Pvt. Ltd.3

In case of Ramachandra Reddy and Co, the court has held that escalation can be granted only either when contract provides for it or when competent authority has agreed to provide for escalation charges by correspondence4. In case of Food Corporation of India, the contractor had made several correspondences with regards to escalation charges, however, the authority never replied to them and kept silent as to whether escalation charges will be paid to contractor.

Where there is a cap on amount that can be claimed as escalation charges

The court in case of N.J. Devani Builders P. Ltd. vs. Indian Farmers Fertilizer Cooperative Ltd, held that in case there is a cap on escalation clause, irrespective of the actual amount of loss suffered, arbitrator cannot award escalation charges more than the amount stipulated in the contract. The court stated that:

"The imposition of limitation on the amount of escalation that the Contractor may claim by a contractual term cannot be said to be a term which offends public policy or to be forbidden by law. In contractual matters, the promisee may desire that the promisor should make a definite promise with regard to the costs to be incurred by the promisee for getting the work done. It is for the promisor to make his own estimation and evaluation on the basis of his experience and to make his offer on that basis, keeping in view the contractual terms"5

Where there is cap on total amount of damages that can be claimed in contract

Where there are clauses in contracts which place limit on total amount of damages which can be claimed irrespective of total loss, the question that surfaces is whether escalation can be asked over and above the damages paid by authority under the clause. An illustration of such clause is given in case of Pt. Munshi Ram and Associates (P) Ltd. vs. Delhi Development Authority and Ors.6

"Clause 22 is also the relevant clause which reads as under:

"All sums payable by way of compensations under any of these conditions shall be considered as reasonable compensation to be applied to this use of Delhi Development Authority without reference to the actual loss or damage sustained, and whether or not any damage shall have been sustained."

While giving interpretation of such clause in terms of escalation, the court held that in such cases also if the contractor has suffered actual loss because of no fault of his own then he is liable to be compensated for the same.

Conclusion

Escalation clause takes care of the rise and fall in price but the parties can always agree that the contractor would not be entitled to any escalation whatsoever or that the contractor would be entitled to escalation limited to a certain amount or a certain percentage of the contract. Such a stipulation is not illegal or inconsistent.7 However, in absence of such stipulation, court will always rule in favor of equity and will not allow party to be unjustly enriched at cost of other.

Footnotes

1. SC) AIR2018SC2961

2. AIR2007SC82

3. AIR2017SC3336

4. Ramachandra Reddy and Co. vs. State of Andhra Pradesh and Ors. (27.02.2001 - SC) AIR 2001 SC 1523

5. N.J. Devani Builders P. Ltd. vs. Indian Farmers Fertilizer Cooperative Ltd. (05.12.2012 - DELHC) 2013IAD(Delhi)205

6. Pt. Munshi Ram and Associates (P) Ltd. vs. Delhi Development Authority and Ors. (07.12.2001 - DELHC) 96(2002)DLT597

7. Supra n 4

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Sign Up
Gain free access to lawyers expertise from more than 250 countries.
 
Email Address
Company Name
Password
Confirm Password
Position
Industry
Mondaq Newsalert
Select Topics
Select Regions
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions