Hong Kong: Concurrent Delays, Global Claims And Particulars Of Claim

Last Updated: 6 August 2012
Article by Kevin R. Owen and Menachem M. Hasofer
Most Read Contributor in Hong Kong, November 2017

An important judgement was recently delivered by Akenhead J in the Technology and Construction Court in London in the case of Walter Lilly and Company Limited v Giles Patrick Cyril Mackay (and Another).


The judgement was delivered on 11 July 2012 and is over 200 pages long. It covers a range of issues arising out of a construction project in London that went badly wrong. While the facts of the case are complex, suffice to say that the case involved the usual disputes between an Employer and Contractor in respect of claims for late completion and defective work on the one hand and claims for extensions of time and loss and expense on the other.

Akenhead J took the opportunity to review the authorities on a number of issues in his judgement but the three matters referred to in the heading of this Alert are of particular interest. They will be dealt with briefly in turn below.

Concurrent Delay

A number of approaches have been adopted by the Courts over the years in dealing with concurrent delays, that is, where 2 causes of delay operate concurrently and where the Contractor is entitled to receive an extension of time under the Contract for one of the causes, but not the other.

In the 1980s and 1990s, there was a body of opinion that held that a Contractor was required to establish that the cause for which he was entitled to receive an extension of time was the "dominant cause" of the delay. This was the approach adopted in Fairweather v London Borough of Wandsworth (1987).

This approach was also adopted by the Scottish Courts as recently as 2010 when, in the decision in City Inn Limited v Shepherd Construction, it was held that whether or not the dominant cause is a "relevant delay event" will determine if a claim for an extension of time is successful. The decision, however, went further and stated that it is open to a certifier or tribunal to apportion the delay between the two causes and that the Contractor should only receive an extension for a reasonably apportioned part of the concurrently caused delay.

This is the so called "apportionment" approach.

The English Courts have, however, chosen not to adopt this method. Instead, they have held that by applying the prevention principle, if there are two concurrent causes of delay, the Contractor is entitled to receive an extension of time for the "relevant event" entitling an extension of time under the Contract, notwithstanding the concurrent effect of the other event.

This was the position adopted by Dyson J in Henry Boot Construction (UK) Limited v Malmaison Hotel in 1999 and by Edwards Stuart J in De Beers v Atos Origin IT Services UK Limited, in 2011.

This approach was endorsed by Akenhead J in the Walter Lilly case where he stated:

"I am clearly of the view that where there is an extension of time clause such as that agreed upon in this case and where a delay is caused by 2 or more effective causes, one of which entitles the Contractor to an extension of time as being a "relevant event", the Contractor is entitled to a full extension of time."

Such a conclusion was reached not only on the basis that "relevant events" would otherwise amount to acts of prevention and that it would be wrong in principle to deny the Contractor a full extension of time but also as a matter of interpretation of the extension of time provision contained in Clause 25 of the JCT Form of Contract.

Akenhead J went on to state that there is nothing in Clause 25 which suggests that an extension of time should be reduced if there is a concurrent delay and although the Architect had a duty to award a "fair and reasonable" extension of time, this does not mean that there should an apportionment as between two concurrent delays.

In concluding, Akenhead J stated that the City Inn case is "inapplicable within this jurisdiction".

Global Claims

The Defendants in Walter Lilly had argued that a number of the claims advanced by the Contractor consisted of "global" claims and, as a result, were barred by authority.

Akenhead J took the opportunity to review the law which has developed on this issue over the last 50 years or so starting with Crosby v Portland UDC in 1967, London Borough of Merton v Stanley Hugh Leach (1985)`` , Wharf Properties Limited v Eric Cumine Associates (1991) and the Australian case of John Holland Construction and Engineering Pty Limited v Kvaerner J R Brown Pty Ltd (1996) .

In drawing together all of the threads of the previous authorities, Akenhead J concluded, in summary:

  1. it does not have to be shown by a Contractor that it is impossible to prove cause and effect between a delay event and losses incurred or that such impossibility is not the fault of the party seeking to advance the global claim. In the absence of contractual restrictions on global loss claims, the Contractor simply has to prove its case on a balance of probabilities;
  2. it is open to a Contractor to prove its entitlement with whatever evidence will satisfy the tribunal and the requisite standard of proof and there is no set way for Contractors to prove the elements of its claims;
  3. there is nothing in principle "wrong" with global or total cost claims. However, there are added evidential difficulties which a Contractor has to overcome and it will generally have to establish, on a balance of probabilities, that the loss which it has incurred would not have been incurred in any event (eg if its tender was so low that the loss would have occurred irrespective of the events relied upon by the Contractor);
  4. the fact that one or a series of events which are at the risk of the Contractor caused or contributed to the total or global loss does not necessarily mean that the Contractor can recover nothing;
  5. a Court will not usually allow global or total cost claims if the actual costs attributable to individual loss causing events can be readily and practicably determined. While a tribunal will be more sceptical about a global cost claim if the direct linkage approach is readily available but not deployed, this does not mean that a global claim should be rejected out of hand; and
  6. the decision in Merton and John Holland did not establish that a global award should not be allowed where the Contractor has himself created the impossibility of disentanglement of loss attributable to each head of claim.

Particulars of Claims

Akenhead J examined the two conditions precedent contained in Clause 26 of the JCT Form of Contract which required, first, the submission of a timely application to the Architect that it had incurred or is likely to incur direct loss and expense and, secondly, the provision of details of loss and expense to enable an ascertainment to be made by the Architect or Quantity Surveyor.

In examining what information must be provided in each case, Akenhead J stated that it is legitimate to bear in mind what knowledge and information the Architect already has.

For example, if the Architect attended meetings regularly and had received numerous applications for extensions of time from a Contractor, it could be legitimately argued that the Architect already had a substantial amount of information available to him. The Contractor would therefore be required to produce less information to enable the Architect to form an opinion that loss and expense had been incurred or was likely to be incurred.

Akenhead J went on to state that Clause 26 of the JCT Contract only required the submission of details "reasonably necessary" for the ascertainment of loss and expense. Accordingly, there was no reason to believe that an offer to the Architect or the Quantity Surveyor to inspect records at a Contractor's office could not be construed as submission of details of loss and expense. He emphasised that all that was required by the clause was the provision of "details" of loss and expense which would not necessarily include all back-up accounting information which might support such detail.

Akenhead J concluded that there was no need to construe Clause 26 in a strict way or in a way which was penal against the Contractor, in particular where the grounds contained in Clause 26 giving rise to a loss and expense entitlement are the fault and at the risk of the Employer.

In relation to providing details of extended preliminaries, for example, the Judge stated that it is legitimate to bear in mind that the Architect and the Quantity Surveyor were not strangers to the project in considering what was needed for them to carry out an ascertainment. As a very detailed breakdown of preliminary items was already included in the Contract at the time of its award, it could be argued that the Architect and the Quantity Surveyor could value the Contractor's loss and expense simply by reference to the Contract rates and prices for a longer period than that which was anticipated at the time that the Contract was concluded.

The Judge rejected the argument advanced by the Employer that in order for the Architect or Quantity Surveyor to "ascertain" loss and expense, it must produce all material evidence necessary to prove its claim beyond reasonable doubt.

The words included in Clause 26 should be construed, he held, in a "sensible and commercial way that would resonate with commercial parties in the real world". All the Contractor had to do was to put the Architect or Quantity Surveyor in a position where they can be satisfied that all or some of the loss and expense claimed is likely to be or has been incurred.


There is no doubt that Akenhead J's judgement in Walter Lilly is an important one. It deals with a number of the "old chestnuts" that preoccupy construction practitioners and also demonstrates a pragmatic and commercial approach by the Courts in dealing with Contractors' claims rather than a strict legalistic one.

It is reasonable to believe that the decision in Walter Lilly will be regarded in years to come as one of the landmark decisions of the Technology and Construction Court.

Originally published 30 July 2012

Keywords: Walter Lilly, Giles Patrick Cyril Mackay, construction,

Learn more about our Singapore office, Hong Kong office, and Construction & Engineering practice.

Visit us at www.mayerbrownjsm.com

Mayer Brown is a global legal services organization comprising legal practices that are separate entities (the Mayer Brown Practices). The Mayer Brown Practices are: Mayer Brown LLP, a limited liability partnership established in the United States; Mayer Brown International LLP, a limited liability partnership incorporated in England and Wales; Mayer Brown JSM, a Hong Kong partnership, and its associated entities in Asia; and Tauil & Chequer Advogados, a Brazilian law partnership with which Mayer Brown is associated. "Mayer Brown" and the Mayer Brown logo are the trademarks of the Mayer Brown Practices in their respective jurisdictions.

© Copyright 2012. The Mayer Brown Practices. All rights reserved.

This article provides information and comments on legal issues and developments of interest. The foregoing is not a comprehensive treatment of the subject matter covered and is not intended to provide legal advice. Readers should seek specific legal advice before taking any action with respect to the matters discussed herein. Please also read the JSM legal publications Disclaimer.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:
  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.
  • Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.
    If you do not want us to provide your name and email address you may opt out by clicking here
    If you do not wish to receive any future announcements of products and services offered by Mondaq you may opt out by clicking here

    Terms & Conditions and Privacy Statement

    Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

    Use of www.mondaq.com

    You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.


    Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

    The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.


    Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

    • To allow you to personalize the Mondaq websites you are visiting.
    • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
    • To produce demographic feedback for our information providers who provide information free for your use.

    Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

    Information Collection and Use

    We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

    We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

    Mondaq News Alerts

    In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.


    A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

    Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

    Log Files

    We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.


    This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

    Surveys & Contests

    From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.


    If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.


    From time to time Mondaq may send you emails promoting Mondaq services including new services. You may opt out of receiving such emails by clicking below.

    *** If you do not wish to receive any future announcements of services offered by Mondaq you may opt out by clicking here .


    This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

    Correcting/Updating Personal Information

    If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

    Notification of Changes

    If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

    How to contact Mondaq

    You can contact us with comments or queries at enquiries@mondaq.com.

    If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.

    By clicking Register you state you have read and agree to our Terms and Conditions