Germany: Provisions Of The New FIDIC ‘Emerald Book'

Last Updated: 18 July 2019
Article by Fabian Bonke, LL.M. (LSE)

After five years of significant work, the new FIDIC 'Conditions of Contract for Underground Works', the so-called 'Emerald Book', was finally published on 7 May 2019 at the World Tunnel Congress in Naples, Italy. This new contractual standard for the tunnelling industry was developed by the International Federation of Consulting Engineers (FIDIC), in cooperation with the International Tunnelling and Underground Space Association (ITA), through the jointly established Task Group 10 on 'Contract Form for Tunnelling and Underground Works'. This article will take a closer look at the provisions of the 'Emerald Book'. The book aims to mitigate the risks inherent in underground projects that arise from the uncertainties ever-present in the subsurface space.

Mastering the challenges

It was generally accepted that a different approach to contracting for tunnels and other subsurface construction projects had to be taken. However, thus far, there was no general common position within the industry on the specific contractual approach that should be taken. To date, the Parties have had to use a "piecemeal approach" and choose from various different options. Occasionally, standard form contracts are used taking other FIDIC books or the New Engineering Contracts (NEC) as a point of origin. The risk allocation between the parties sometimes makes reference to national standards such as the Swiss 'General Conditions for Underground Construction' (SIA 118/198:2007), last updated in 2007. Additional guidance can also be obtained from the various Recommendations, Guidelines and Checklists produced by the ITA.

Contractual arrangements differ from project to project and are often drafted specifically for the relevant project. A thorough planning of these works, as well as a correspondingly forward looking contractual framework, are crucial for the realisation of tunnels and other subsurface construction projects. Advanced planning is often limited due to financial and legal constraints as the subsurface space is vast, difficult to access and often in the hands of a multitude of owners. Tunnelling and other subsurface projects are also increasingly complex due to a higher demand for project delivery in geographically challenging environments and increased expectations for the utilisation of such projects after completion. While performance of the work in the subsurface space is under way, the geological, geotechnical and structural conditions of that space often prove to be different than initially anticipated. In these circumstances, the involved parties are met with unpredictable challenges which often lead to a loss of time, trust and resources that are not found in other projects, and which consequently lead to costly disputes. These unforeseeable risks caused by the ground conditions are unique in terms of risk management and risk allocation in construction contracts. The availability of a comprehensive contractual standard has long since been expected to tackle these challenges, improve legal predictability for the industry and, in doing so, sustain growth in the market.

Background of the 'Emerald Book'

The ITA has emphasized for decades the key role of contractual provisions in tunnelling and other subsurface construction projects. In 1974, the ITA established a Working Group on Contractual Sharing of Risks (today ITA Working Group 3). The Working Group has since published recommendations on a large variety of contractual topics. One key concern has been finding ways to equitably distribute underground risk between owner, contractor and consultant. The recommendations further dealt with, inter alia, clauses on changed conditions; full disclosure of available subsurface information or the pre-qualification of contractors.

Additionally, from the 1970's, ITA officials started discussions with representatives of FIDIC to include the ITA recommendations into the FIDIC Conditions of Contract. These Conditions of Contract published by FIDIC are the most frequently used contractual forms for international infrastructure projects worldwide. FIDIC has published a variety of different Conditions of Contract which are now (unofficially) referred to according to the colour of their bindings: most renowned being the 'Red Book' and the 'Yellow Book'.

In recent years FIDIC has published many new Conditions of Contract. The process leading to the 'Emerald Book' started in 2014 with the setting up of the jointly established Task Group 10 'Contract Form for Tunnelling and Underground Works'. After extensive stakeholder consultations in the aftermath of the first draft, the final edition of the 'Emerald Book' was drafted and adopted in the spring of 2019.1

General structure of the 'Emerald Book'

Despite being established as a self-standing FIDIC book, the 'Emerald Book' uses FIDIC's 'Yellow Book' as its blueprint. Correspondingly, 90% of the clauses of the 'Yellow Book' are transferred without any changes into the 'Emerald Book'. After introductory notes, the 'Emerald Book' is structured into three main parts: (1) The General Conditions of Contract are followed by (2) Guidance for the preparation of Particular Conditions, and (3) Guidance for the Preparation of Tender Documents and Annexes completed by various standard forms with relevance in tunnelling and other subsurface construction projects. The General Conditions are composed of a total of 21 clauses covering definitions, risk allocation between the parties, their obligations and liabilities, dispute resolution and other provisions relating to the employer, the engineer and the contractor. Based on the general distribution of risks in the 'Yellow Book', the 'Emerald Book' follows suit and assigns the general risk of performance to the contractor as he already assumed the design of the relevant tunnelling or other subsurface project. However, the parties can also agree on establishing their contractual relationship on a design of the project which has been previously completed by the employer. While generally suggesting not to do so, the Guidance for the preparation of Particular Conditions provides recommendations for the process of adapting specific provisions in ascending order of the General Conditions.

The 'Emerald Book' can also easily be applied to all common excavation methods, specifically blasting and mechanized tunnelling using special TBMs. The close link to the 'Yellow Book' will also facilitate the use of the 'Emerald Book' as the baseline for additional contracts between the contractor and his sub-contractors in relation to the fulfillment of the main contract.

Risk allocation in the 'Emerald Book'

The 'Emerald Book' introduces a new model for managing the risks that are peculiar to tunnelling or other subsurface construction works. It would be unbalanced if all risks arising out of unforeseeable subsurface conditions would be assigned to the contractor in the same way as the general risk of performance lies with the contractor. Therefore, the 'Emerald Book' includes a set of clauses deviating from the standard of the 'Yellow Book'. The background principle is that the parties should define the subsurface conditions of the relevant tunnelling or other subsurface construction project as detailed as possible. Through this, a mutually-agreed level of expectancy is created. At the same time the parties acknowledge that not all of the subsurface conditions can be determined with sufficient precision in advance.

Thus, the risk that such unforeseeable conditions would occur lies with the employer as the party who can best control such risks. This is justified since the employer benefits most from the completed project. Consequently, the employer should face adjustments to his expense if the subsurface conditions are worse than first anticipated. But the employer should similarly also benefit if the conditions are better than first anticipated.

In turn, the risks deriving from expected subsurface conditions are assigned to the contractor, as well as the production rates and the general cost of performing the works under unchanged conditions. The contractor can best handle expected ground conditions due to his experience and specialist knowledge in adjusting design and construction to such conditions.

GBRs and Baseline Schedule

The mutually agreed level of expected ground conditions is created through the inclusion of a geotechnical baseline into the relevant contract. For this aim, the 'Emerald Book' provides for a 'Geotechnical Baseline Report' ('GBR'). The 'GBR' sets out the subsurface conditions anticipated under the contractually agreed underground excavation and lining design as well as the construction methodology.

The 'GBR' shall be incorporated as an integral part of the contract and not just added as a reference. The Parties should exercise great care in drafting the 'GBR'. The contractor will contribute to the 'GBR' his proposal for a feasible method of the tunnelling or other subsurface construction work, distinguishing between excavation and lining works. The corresponding items and activities for the works, including the respective production rates, shall be combined in at least one additional baseline schedule.

Adjustments of time for completion and contract price

The underlying allocation of risks between the employer and the contractor also explains the provisions of the 'Emerald Book' on adjustments of the completion time and the contract price. Due to unforeseeable or unexpected subsurface conditions, the completion schedule might be exceeded. Accordingly, the previously agreed lump sum for the project might not be sufficient to cover the contractor's cost and profit. In these situations, the 'Emerald Book' offers flexibility to the parties through various time and price adjustment mechanisms. The applicable set of rules depends on whether unforeseeable or unexpected subsurface conditions occur during the execution of the project.

For unexpected subsurface conditions a new provision, unique to the FIDIC Books, was introduced in the 'Emerald Book' to adapt the completion time and the contract price. Thereafter, if unexpected subsurface conditions occur during the execution of the project, the contractor is required to measure the actual excavation and lining works. In order to determine the possible adjustment(s), the records of the measurement will be compared to the excavation and lining works as set out in the initial baseline schedule(s) which were derived from the expected subsurface conditions of the parties in the 'GBR'. The resulting difference in time or cost will then determine the level of adjustment(s). This could lead to the outcome that the contractor might be entitled to ask for an extension of the completion date or additional payments. But if the encountered conditions are better than those expected in the 'GBR', the completion time can also be shortened as well as the contract price reduced. By this, the employer can also benefit from encountered subsurface conditions and not only the contractor.

Role of the Engineer

In line with other FIDIC Books, the 'Emerald Book' also has a strong role for the engineer in place. He is facing a role conflict in the book as he is acting, on the one hand, as the employer's agent and, on the other hand, as a neutral and independent body with the power to agree or to determine specific matters. This dual role requires a high degree of impartiality and fairness from the side of the engineer. The engineer undertakes a broad range of activities in the context of the correct day-to-day administration of the project.

In order to further accommodate the specific challenges of tunnelling and other subsurface construction projects in the 'Emerald Book', the engineer has specific supervisory and monitoring duties and authority for excavation and lining works. His central role in resolving disputes is also underlined in the 'Emerald Book' when it comes to adjustments following unexpected subsurface conditions. In this regard, the engineer has to confirm or reject the contractor's measurement of his excavation and lining works on which adjustments can solely be based. In addition, the engineer also determines the relevant adjustments of the completion time and the contract price.

Claims and disputes

In order to achieve clarity for the parties, claims under the 'FIDIC Book' are subject to relatively short cut-off periods and relatively complex procedures. The same applies to the procedure for the resolution of potential disputes arising from the claims, which in line with the other FIDIC books, consists of a multiple steps: A dispute is determined by the engineer, which in case of one party's dissatisfaction can be referred to the Dispute Adjudication/Avoidance Board (DAAB). As is the case with the current FIDIC standard, the DAAB is appointed permanently for the term of the project and not ad hoc for one single dispute. The DAAB renders a temporarily binding decision. The party dissatisfied with the DAAB decision might seek a last attempt at dispute avoidance and an amicable settlement may be reached. The dispute may be referred to arbitration governed by the rules of arbitration of the International Chamber of Commerce (ICC) where the dispute would be finally settled.

This provided dispute resolution mechanism has already proven to be successful in the other FIDIC books. The availability of a standing DAAB assists in avoiding disputes and provides for quick decisionmaking which is essential in large construction projects. Claims and disputes, however, have to be pursued within the applicable time limits, which requires a sophisticated contract and claim management by the parties.


The new 'Emerald Book' is a promising model contract for the tunnelling industry as it addresses the biggest challenges of tunnelling and other subsurface construction projects. Based on international best practice derived from the comprehensive experience of FIDIC Conditions of Contract, the 'Emerald Book' could become a global contractual standard. It has the potential to create enhanced legal predictability in tunnelling projects and thus will contribute to economic growth in the business sector as a whole. However, the parties will have to continue to look deep into the details and find a tailor-made solution based on the specific characteristics of the relevant project. The 'Emerald Book' will provide the parties with the right starting point for the contractual arrangement for their project. In order to facilitate an adaptation of the general body of rules, the new FIDIC book will provide valuable guidance in its FIDIC Particular Conditions, which can be used to modify the General Conditions. It is, however, of paramount importance that no ambiguity is created, either with the General Conditions or between the clauses in the Particular Conditions.

But the parties will still need to seek for tailor-made advice to conduct a risk assessment of the 'Emerald Book' concerning the applicable contract law. The 'Emerald Book' only functions as a model for their future contract. Thus, issues such as the interpretation and validity of its provisions are to be determined according to the applicable contract law. And national laws might find different interpretations for the very same wording. In rare occasions, the governing national law might even override provisions of the 'Emerald Book' or any other FIDIC template. This is especially relevant for provisions on damages or limitation of liability which are often critically viewed under national contract laws and therefore require careful consideration.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Topics
Related Articles
Up-coming Events Search
Font Size:
Mondaq on Twitter
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions