Canada: Adding Up Cost Of Construction Delays

Last Updated: September 26 2019
Article by Ephraim Stulberg and Cameron McQuaid

No one likes delays. Whether it's a rain delay at a sporting event or a subway delay stuck somewhere beneath the city of Toronto, delays cost us time that we would rather have spent doing something else. Sometimes, however, delays can cost not only time, but money as well. In this article, we discuss some of the key issues in calculating economic losses in construction delay claims.

Construction delays can occur for a wide variety of reasons. Sometimes they are caused by negligent work performed by a trade or technical expert that needs to be rectified; sometimes they are caused by unforeseen physical damage to the project. Whatever the reason for the delay, it means that things did not happen when they were supposed to happen.

The Concept

The end goal in these types of claims, as in any economic loss calculation, is to measure the difference between a) the level of profit the plaintiff would have earned based on revenues and expenses that would have occurred but for the delay, and b) the actual profit the plaintiff achieved following the delay.

The Chronology

A key component in this measurement is establishing the timelines of the project and the impact of the alleged wrongdoing or event on that timeline.

While sometimes this issue is relatively clear cut, in other cases it can be very complex, as it may be possible for a delay in one area of a project to be offset by an acceleration of work in other areas. Moreover, the overall project may have also been affected by other, unrelated delays that will have impacted the projected completion date and the corresponding impact on the project's profitability. This is an area where we, as forensic accountants, are often assisted by other experts.

Delays in completion of a construction project can create a variety of types of economic loss. Below are some common types of economic losses that result from construction delays.

Soft Costs

The longer a project carries on, the longer the developer will incur time-related costs. These costs can include rental costs for temporary facilities and equipment, insurance and bonding costs, property taxes as well as financing costs including both renewal fees for loan facilities and the interest on those facilities. Some of these costs are only applicable if the developer plans to sell the building upon completion; others apply in all cases.

It is important to understand the direct impact of a delay on these costs. For example, a delay in the construction schedule will mean that disbursements of construction loan facilities (which are often set up as a "revolving loan" where interest is only charged on the amount used by the developer, similar to a line of credit ) are delayed as well. The delay should generally be measured based on the loan balance at the time the delay occurs, rather than at the end.

Acceleration costs

In some cases, a construction delay can cause the cost of certain work to increase. If exterior work that was planned to be performed in the summer is delayed to the winter, this can create higher costs. Similarly, if schedules are expedited following the resolution of the delay, then there may be a higher than planned level of overtime expenses incurred.

Loss of rents

If the project is a property that will eventually be leased to tenants, a delay in completion can result in lost rents, as well as costs to find temporary accommodation for tenants who were
planning to occupy the new space and cannot continue to lease month-to-month.

Again, in analyzing such potential losses, it is important to isolate those rental losses that are causally related to the delay. For example, if following the completion of the building it is only 60 per cent occupied for a long period of time, then it is unlikely that the failure to lease the remaining 40 per cent is related to the delay.

Losses of rents can also occur in condo building projects. Typically, it is possible for a condo project to achieve interim occupancy several months before substantial completion of the project and the final closing dates of the sale of units. During this interim occupancy period, the future condo owner lives in their condo, although they do not officially own it yet, and the monthly payments made to the developer during this period do not pay down the condo owner's mortgage on the property. An assessment of whether a construction delay impacted the interim occupancy payments collected by the developer is necessary when determining the economic loss.

Loss on selling price

This is an area that can sometimes arise in volatile real estate markets. A delay in completion of a project may result in a reduction in the ultimate selling price the developer is able to achieve on the project.

Penalties

In some situations, there can be severe penalties for failure to meet construction deadlines. These are not difficult to quantify; the challenge is in determining whether the plaintiff would have managed to avoid these costs even absent the particular delay in question.

Conclusion

In the short space of this article, we have only been able to present a broad outline of some of the major areas we encounter in quantifying construction delay claims. Every case will have its own nuances, but the principles underlying the quantification approach will remain the same.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
 
In association with
Related Topics
 
Related Articles
 
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Mondaq Free Registration
Gain access to Mondaq global archive of over 375,000 articles covering 200 countries with a personalised News Alert and automatic login on this device.
Mondaq News Alert (some suggested topics and region)
Select Topics
Registration (please scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions