Canada: Notice Of Delay: Simon Says, "I Am Making A Claim."

Last Updated: January 9 2018
Article by F. Richard Gosse

Contrary to the perception that lawyers thrive in loopholes, when a dispute arises, the concepts of fair and reasonable are consistent.  It is on that basis that most parties are able to work through disputes without commencing litigation.  It is also why people get worked up when the issue raised is whether there was formal notice under the contract, or when Simon says, "I am making a claim."

By reputation, "notice of delay" remains shrouded as if it were a rule to be followed only for the rule's own sake.  After all, everyone knows when a job is behind schedule.  The concern over the notice requirements for claims of contractor delay are rooted in contract: for example GC 6.5 of CCDC 2 or GC 8 in the standard front end documents set by the Newfoundland and Labrador Department of Municipal Affairs and Environment expressly oblige contractors to give notice in writing within days after the commencement of the delay.

Intuitively, the notice requirement is daunting to most: in addition to compounding an already stressful situation, putting the other side on formal notice could burn bridges. After all, when someone is pushing you because you are behind, they already know that you have been delayed.  The argument is: 'we know you have not met your schedule; we didn't know that you were going to charge us for that.'

Embar Construction Ltd. v. Newfoundland 

Understanding when delay is "actionable" (or can sustain litigation and result in damage awards) is the first step in rationalizing the process; the 1995 decision of Embar Construction Ltd. v. Newfoundland (Minister of Works, Services and Transportation) explains that:

In most such projects, delays are a common occurrence and ... it is not enough to show that there had been delay, but that there was in this case "actionable" delay. ... [I]t must be clearly demonstrated that the delay was caused by the act of the owner or another contractor and, most importantly, ... that the delay resulted in additional costs or expenses being incurred by the claimant attributable to that delay ... [and] ... that the contractor's forces could not have worked efficiently elsewhere on the project.  ...  In other words, not only must it be demonstrated that a delay occurred which was the fault of the owner or another contractor, unavoidable loss or damage must be demonstrated to have been the result thereof. 1

The Court in Embar explains prompt notice under the contract as a common sense requirement on the basis that the claimant could not proceed and damages could not be avoided:

... It is obviously equally important that any such claim for delay be brought to the attention of the other party immediately in order that a resolution may be at least attempted in an expeditious manner; this is the very reason for the time limitation. ... One can fairly say that experienced contracting parties would either make or expect to have made against them any such claims as soon as they occur and with sufficient detail to place on the record that the claim is a valid one.2

Corpex (1977) Inc. v. Canada

The Embar approach is consistent with the Supreme Court of Canada decision in Corpex (1977) Inc. v. Canada, which 35 years ago ruled that the notice requirement benefits both the contractor and the owner but that benefit is denied when notice is not given.  Notice initiates a process for the contractor to respond to its frustration and delay, and for the owner to explore alternatives in how the work can proceed with minimal delay and have opportunity to verify or challenge circumstances before claims are fully developed.  The presumption is that, if there is an issue, everyone impacted should have an opportunity to address it head-on and should not be prejudiced if no one speaks up.3

While generally referenced in relation to who bears the risk for change in conditions, Corpex is still followed re notice obligations. Current case law confirms that the argument can still be particularly effective in efforts to strike down delay claims at a preliminary stage without the need of a full trial 4 or as a full answer to a delay claim.5

Know Your Contract

Notice is more than a game of "Simon Says" and lack of notice does not always bar a delay claim if the court can find that there was actual or constructive notice.  Whether the contractual obligation to provide notice has been met can be very fact-specific: the issue is in understanding what the contract actually provides and what evidence is made available.  For example, minutes of meetings (especially where detailed and circulated for review and correction) can demonstrate if a party has adequately communicated concerns.  Details that seem monotonous, like repeated issues around access to the site, structures, utilities under or above-ground, or about other forces or outstanding decisions from the owner, can be taken as a contractor (a) carefully listing concerns, (b) asking for action and (c) indicating a clear intention to claim or demand the appropriate remedy.   A Court can consider this to be notice, but it cannot make that determination until it sees the witnesses and evaluates all of the evidence to gain an appreciation of the relevant circumstances – a notice letter is generally a more efficient tool.  Rather than gamble on how strictly a contract might be read or actions might be interpreted, best practice is to follow the contractual provisions and clearly explain in writing the cause for concern, how it needs to be addressed and what will result, especially as relates to costs. 

Formal notice can ratchet-up an already tense situation, but it can also help provide a road map for what needs to be done to diffuse issues.  Even when damages cannot be predicted with any degree of accuracy, experienced parties usually know when increased costs are likely and, in most cases, the simple fact that costs are increasing can be as significant as the exact figures.  Often, an external resource can prepare the notice on your behalf, or can help you find the words to better prepare the notice yourself.   Early legal advice can be a valuable investment, especially where specific terms are part of the issue.  While it may seem like an exercise in navigating loopholes, formal notice usually makes sense as an opportunity to mitigate delay and keep increasing costs in check.  It is not always obvious, but more people are looking for a resolution than for litigation.

Richard is a partner at the St. John's office, practising in commercial litigation with a focus in construction. He serves as the Construction Law Section Chair of the Canadian Bar Association (NL Branch) and is co-chair of Cox & Palmer's Construction Law Group. 


1 [1995] N.J. No. 108 at paragraphs 15-16

2 [1995] N.J. No. 108 at paragraphs 25-26

3 [1982] S.C.J. No. 91

4 For example Limen Structures Ltd. v Brookfield Multiplex Construction Canada Limited, 2016 ONSC 5107

5 Such as in Construction Cogerex ltée c. Dawalibi Investissements inc., 2017 QCCS 1817

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on

Click to Login as an existing user or Register so you can print this article.

In association with
Related Topics
Related Articles
Related Video
Up-coming Events Search
Font Size:
Mondaq on Twitter
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
Email Address
Company Name
Confirm Password
Mondaq Topics -- Select your Interests
 Law Performance
 Law Practice
 Media & IT
 Real Estate
 Wealth Mgt
Asia Pacific
European Union
Latin America
Middle East
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of

To Use you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.


The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.


Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions