Canada: Top 10 Issues In Alberta's Renewable Electricity Support Agreement For Developers And Lenders

On November 10, 2016, the Alberta Electric System Operator (AESO) released a draft summary of terms for its Renewable Electricity Support Agreement (RESA) for review and comment. The comment period runs until December 9, 2016.

As noted in our November 2016 Blakes Bulletin: Details of Alberta's Renewable Electricity Program: Program to Add 5,000 Megawatts of Capacity by 2030, the Alberta government is moving forward with the implementation of a Renewable Electricity Program (REP), the purpose of which is to encourage the development of 5,000 megawatts of renewable electricity generation capacity in Alberta between now and 2030.

The REP provides that successful bidders with eligible projects (known as Generators) will each enter into a RESA with AESO consisting of two periods — a development and construction period followed by a 20-year support period.

This bulletin identifies key issues for developers and lenders under the draft RESA terms as presented, with a particular focus on how the RESA terms differ from those in other key Canadian markets.

  1. Pre-Construction Requirements

Under the RESA, a Generator will be deemed to have commenced construction only once it has satisfied the specific requirements set forth therein. This has important ramifications given the RESA's parallel requirement that construction commence by a certain date and the rights given to the AESO to terminate the RESA (and draw upon the Generator's performance security as liquidated damages) if construction is not in fact commenced by a longstop date (anticipated to be December 2019 for the first procurement, subject to extension for Force Majeure (as defined in the RESA) or certain changes in law). Commencement of construction of a facility will be deemed to have been achieved at the point when (as subsequently confirmed by the AESO in writing) the Generator has:

  1. Obtained key Alberta Utilities Commission (AUC) and other environmental, assessments, permits, licences and approvals
  2. Delivered a statutory declaration to the AESO confirming the Generator has secured financing sufficient to complete development, construction and commissioning of the facility, procured or entered into arrangements for long-lead equipment and materials that are necessary for the construction of the facility and commenced construction activities at the site of the facility
  3. Delivered a copy of its financial model to the AESO

These requirements — particularly those regarding equipment and materials — are stringent and go beyond those in place in other jurisdictions.

  1. AESO Security

Notably, the RESA contemplates the AESO taking a security interest over the entire project to protect against default by the Generator. While detailed provisions have not been provided in this regard in the summary of terms provided to date, understanding the genesis and scope of the proposed security to be held by the AESO, its rights to enforce such security in the event of a generator default and its interaction with third-party lender rights will be key to getting Alberta renewable energy projects financed. While some of the language under the heading "Financing and Consequences of Default" used in the term sheet reads in a similar fashion to the analogous provisions of the Ontario Feed-in Tariff (FIT) and Large Renewable Procurement (LRP) contracts, it is unclear exactly what terms the RESA will contain. Similarly, prospective financiers will be keen to see the prescribed form of consent and acknowledgment agreement that will accompany the RESA in order to see that it provides the usual protections that funders would be used to seeing in renewable energy projects in other markets.

  1. Curtailment

Significantly, the RESA does not provide Generators with a right to seek compensatory payments if they are directed by the AESO to dispatch off, irrespective of generating ability. This is a position unlike that of developers currently under LRP contracts in Ontario and similar agreements in British Columbia, where a risk-sharing approach to economic curtailment has been implemented in order to assure the financial viability of projects. Coupled with an outright prohibition on Generators selling ancillary services, this lack of compensation poses a real economic risk to developers of renewable projects where there is no offsetting reduction in fuel costs to offer partial relief during curtailments. It remains to be seen whether concerns over curtailment will affect the viability of certain kinds of projects. 

  1. Force Majeure

The scope for claims by the Generator for Force Majeure specifically excludes the inability to procure feed stock or fuel for the facility; any appeal of the permits and licences for the project (unless the Generator is ordered to cease construction); and the inability to obtain any required consent or approval of the AESO required pursuant to the terms of the RESA. While relief in the form of additional time during construction is possible under the Force Majeure heading on the grounds of inability to obtain or renew permits (unless caused by the Generator), certain representations required to be made by Generators in the RESA itself may, as a practical matter, limit claims in this regard given the requirement that the event giving rise to the Force Majeure claim be reasonably unforeseeable. Prior to the commercial operation date (COD) for a project, an event of Force Majeure will provide the Generator with additional time for construction and relief from default. However, if an event of Force Majeure occurs post-COD that impacts the project's ability to produce power, there is no extension of the term of the RESA and accordingly the associated revenues expected to be received from the AESO will be forgone. We do note that either party may terminate in cases of any single event of Generator-invoked Force Majeure that lasts 18 months (or multiple events that last 24 months in aggregate). While the Force Majeure regime proposed for the RESA does not differ significantly from that in the FIT or LRP contracts, all of these considerations will have to be taken into account in developer timelines, economic projections and financing plans.

  1. Change-in-Law

The RESA will include a change-in-law regime that will allow the Generator to claim additional time or payment adjustments in a variety of circumstances, including due to a change to Independent System Operator rules that materially affects the Generator's economics, or due to changes in the market structure. Relief is also planned to be made available due to certain discriminatory changes in law (including amendments to the RESA required by Alberta) that materially delay the development and construction of a facility or that increase costs a Generator would reasonably expect to incur (but we note that a reference to decreased profits is not included). The RESA terms provide that relief will not be provided where the Generator had prior notice of a change or where the change is permitted by the RESA. Of note, however, is that changes to conditions in regulatory permits or licences will not be considered to be changes in law unless, and to the extent, the applicable statutory regulatory provisions change. Furthermore, a change in law will not qualify to the extent that it only applies (or applies earlier) due to the Generator's conduct. Where it is available, compensation is expected to be provided on a "no better and no worse" basis. Seeing the final drafting on these change-in-law provisions will be key to developers evaluating opportunities in the Alberta market, particularly given the Alberta government's recent stance on change-in-law clauses in legacy power purchase agreements.

  1. Facility Modifications

Consistent with the position taken by governments elsewhere in Canada, a Generator under a RESA will not be permitted to materially modify, vary or amend the specifications or features of the subject facility (as set out in the specifications attached to the RESA) without the AESO's consent. It remains to be seen in the final documentation in what circumstances the AESO would be entitled to exercise discretion here, and this could impact the ability of Generators over time to adapt facilities to new technologies.

  1. Termination for Convenience

The AESO maintains a unilateral right to terminate the RESA for convenience that applies both pre-construction and post-construction. For terminations prior to construction commencement, the compensation payable to the Generator includes only qualifying pre-construction costs — the extent of which will need to be better understood. Furthermore, there appears to be a cap on such costs in an amount to be determined in the final RESA. No other amount, including return on equity returns or debt, would be compensated. After construction commencement, it is clear that in addition to decommissioning costs related to winding up the project, project finance debt and termination and breakage costs would be repaid, plus a return on equity to that date. However, it is noteworthy that on a termination for convenience, equity will not be compensated fully for the expected return over the life of the project). This termination risk and the nature of the payments received is something developers will need to understand as it is fundamentally their risk.

  1. AESO Fee

The RESA terms provide that Generators will be required to pay an administration fee to the AESO to cover the AESO's REP development, implementation and administration costs. It remains to be seen whether or not this fee is significant enough to affect project economics.

  1. Dispute Provisions

Unlike other power purchase agreements in Ontario and British Columbia, which contain dispute resolution provisions requiring arbitration, the RESA terms provide that in the event of a dispute that is not resolved within 10 days by the parties' representatives, either party may commence litigation.

  1. Timeline and Administrative Resource Issues

Alberta's proposed schedule to achieve COD for the projects being procured in the REP's first round is very ambitious. The request-for-proposal stage where winning bidders will be awarded a RESA is expected to last two to three months during Q4 2017. Accordingly, it will not be possible for those looking to participate in the Alberta market to begin substantial development and planning work based on an assured contract until 2018. As noted above, the draft RESA terms require that projects forming part of the first round of procurements commence construction in 2019, but achieving that milestone carries with it significant deliverables on the part of Generators, all of which would need to be confirmed by the AESO concurrently with submissions being made under other projects forming part of the first round. The AESO will need to commit significant resources in order to process the number of deliverables contemplated by the REP.

Similarly, the COD date must be confirmed by the AESO with review of a variety of items as a prerequisite to confirmation of COD. Timelines for the proposed projects have to take all of these factors into account. The REP requires projects to be in service in 2019 (subject to the 18-month longstop default). The AESO's six-stage process of interconnection (which it targets to take a cumulative 24 months) will be an impediment to potential Generators meeting this tight schedule. As a result, the successful projects in the REP's first round will likely have to be those which have already received AUC and AESO approvals or have substantially progressed through the AESO interconnection process.

In an effort to accelerate implementation of the REP and have projects in service by the government's target date of 2019, Alberta is only consulting with stakeholders regarding the draft commercial terms of the RESA until December 9, 2016.

While the industry awaits the final form of the RESA, it will also be monitoring the other recent announcements from the Government of Alberta in the power sector, including its plan to switch to a "capacity" market by 2021. In principle, this concept should not interfere with the development and project financing of renewable energy projects and is likely to be well received by developers and lenders. However, more details will need to be known, including the impacts on the market design generally and with respect to the REP.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Events from this Firm
14 Nov 2018, Speaking Engagement, Ontario, Canada

Join members of the Blakes Environmental and Enterprise Risk & Crisis Response groups for a discussion of hot topics and trends in Canadian environmental law.

15 Nov 2018, Webinar, Toronto, Canada

Join us for a live webcast with partners from our Employment & Labour and Litigation & Dispute Resolution groups as they discuss employment-related challenges and considerations surrounding the recent legalization of recreational cannabis in Canada.

15 Nov 2018, Webinar, Toronto, Canada

Join us for a live webcast with partners from our Employment & Labour and Litigation & Dispute Resolution groups as they discuss employment-related challenges and considerations surrounding the recent legalization of recreational cannabis in Canada.

 
In association with
Related Topics
 
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions