Canada: Court Of Appeal Summaries (March 14-18, 2016)

Last Updated: March 24 2016
Article by John Polyzogopoulos

Good afternoon.

This week's decisions from the Court of Appeal covered a broad range of topics, including defamation (the requirements for notice under the Libel and Slander Act), wrongful dismissal, expropriations, several contract interpretation cases, and a family law case, involving whether there was a true loan from a parent to their child.

Have a nice weekend.

CIVIL DECISIONS

Arsenault v. Nunavut, 2016 ONCA 207

[LaForme, Pardu and Roberts JJ.A.]

Counsel:

Michael D. Marin and David Quayat, for the appellant

Jock C. Climie, for the respondent

Facts:

Appellant sued Government of Nunavut for wrongful dismissal. The appellant claims that the alleged harassment by her employer caused her to develop severe mental illness. She filed a report from a psychological associate indicating that a return to Nunavut could trigger her symptoms in legal proceedings. The motion judge ruled the action to be heard in Nunavut. The appellant wants the cause of action to be heard in Ontario, and claims that is the appropriate forum giving her circumstances.

Issues:

Did the motion judge err in failing to conclude that Ontario was a forum of necessity?

Holding: Appeal Dismissed

Reasoning:

No. The Court found no error in the motion judge's decision. The evidence of the psychological associate was that there was a risk of traumatic activation, that it was not advisable for the appellant to return to Iqaluit, and that it would be "especially challenging" for the appellant to return to Iqaluit for a legal proceeding. She did not say the appellant could not return. The court also said that should the appellant make the case by admissible evidence on a motion before a Nunavut court her condition requires her to give evidence from a remote location, the appellant's request could be accommodated.

Canadian Union of Postal Workers v. Quebecor Media Inc., 2016 ONCA 206

[LaForme, Pardu and Roberts JJ.A.]

Counsel:

David Migicovsky and Karin M. Pagé, for the appellant

Tycho Manson, for the respondents Quebecor Media Inc., Sun Media Corporation, TVA Group Inc., and Jerry Agar

Stephen Cavanagh, for the respondent Avi Benlolo

Facts:

The motions judge had dismissed the appellant's action following the respondents' Rule 21 motion. Specifically, the motions judge held that the appellant's notices did not comply with the requirements of ss. 5(1) of Ontario's Libel and Slander Act. While they identified the matters complained of by the appellant, the notices did not sufficiently specify them.

On appeal, the parties agreed that the standard of review of a motion judge's order pursuant to Rule 21.01(1)(a) of the Rules of Civil Procedure is correctness, as these orders determine questions of law. The appellant submitted that the motions judge erred in holding that its ss. 5(1) notices were deficient.

Issues: Did the motions judge err in holding that the appellant's ss. 5(1) notices were deficient?

Holding: Appeal Allowed.

Reasoning:

Yes. The Court in Grossman v. CFTO-TV Ltd. established that ss. 5(1) notices under the Libel and Slander Act do not have to be in a specific form, while the Court in World Sikh Organization of Canada v. CBC/Radio Canada held that it is not necessary for these notices to contain the same level of particularity as required in a statement of claim. Instead, they need to be sufficiently specified so that the notice reveals the essence of the matter complained of by the plaintiff and concomitantly gives the defendant the opportunity to analyze and assess the allegations.

The Court held that the appellant's notices achieved these objectives: the broadcast and article in issue were short and could not reasonably cause confusion. Moreover, they clearly specified the matters complained of and even reproduced actual portions of the allegedly defamatory words.

The respondent Benlolo argued that the notice was invalidated by the inclusion of a retraction notice and draft apology because he could not bring about the retraction as he had no control over the media defendants. The Court rejected this argument and reasoned that the LSA requires only that notice of the matter complained of be given and that there is no requirement that the plaintiff suggest a possible resolution or that the defendant accept any proposal from the plaintiff.

The other respondents' argument that the appellant failed to include the additional allegations pleaded in the statement of claim about the form and placement of the article was similarly rejected. Instead, the Court found that the notice specified the matter complained of and met the requirements of the LSA.

Benlolo's argument that the plaintiff unincorporated trade union had no capacity to bring a suit in defamation was not decided either by the motions judge or by the Court of Appeal, as it was the subject of Benlolo's cross-appeal, which he did not pursue and for which leave was required to the Divisional Court pursuant to Rule 62.02(1) of the Rules of Civil Procedure. That issue is better left to be decided by the trial judge.

1739061 Ontario Inc. v. Hamilton-Wentworth District School Board, 2016 ONCA 210

[Feldman, Lauwers and Benotto JJ.A.]

Counsel:

Frank Sperduti and Christel Higgs, for the appellant

Paul R. Henry, for the respondent

Facts:

The School Board operated a secondary school on a property (the "Property") for 33 years until declining enrolment led it to close the school and to sell the Property to the appellant. The appellant intended to redevelop the old school building as a seniors centre. The School Board then changed its mind and decided to close other secondary schools in the area and build a centrally located school on the Property it had sold to the appellant. When the appellant would not sell the Property to the School Board at what it viewed as a fair price, the School Board expropriated the Property from the appellant.

The School Board subsequently authorized its staff to implement a land swap with the City whereby a large portion of the Property would be exchanged for City lands adjoining the Property in a joint development plan to build a school with accessibility to ancillary facilities. However, the swap had not been executed, only approved. The appellant asserted that the School Board's actions triggered ss. 41(1) of the Expropriations Act, and the School Board was required to offer to re-convey the Property to it.

The application judge accepted the School Board's submission that it is essential and fundamental to the creation of shared services that "related amenities" be interpreted broadly enough to include the development of the Property to be completed by the City rather than the School Board. The application judge also accepted the submission that s. 41 was not triggered because the Property had not been found to be no longer required for the School Board's purposes, which include a pool and recreational facility. Lastly, the application judge did not find that the School Board was obligated to offer the Property back to the appellant, and that the School Board had met its obligations under the Education Act.

Issues:

(1) Are the appellant's rights under s. 41 of the Expropriations Act engaged on the facts, and if so, what are the consequences?

2) Is the School Board required to offer the Property back to the appellant under s. 41 of the Act despite its resolution not to do so under s. 42 of the Act?

3) Did the application judge err in his award of costs to the School Board?

Holding: Appeal dismissed, costs appeal allowed.

Reasoning:

(1) No. The School Board's actions did not trigger the offer-back obligation in ss. 41(1) of the Expropriations Act. There was no merit in the appellant's argument that the School Board's expropriation was actually done for the benefit of the City and its purposes.

The court found it must take a purposive approach to the interpretation of the Act, not a "strict construction" approach. While the court agreed that the School Board was not permitted to change the purpose for the expropriation, it found the School Board did not do this, nor did it act as an agent for the City in expropriating the Property. The court found it was not its function, nor that of the Expropriations Act, to micromanage the School Board's actual use of the Property, so long as it is used as part of a school site or related amenities owned by the School Board.

Further, since the Board had not finally decided to swap lands with the City or permit the construction of a City-owned facility on the Property, the question of the proper application of s. 41 of the Expropriations Act was premature for the court to decide.

(2) The court declined to rule definitively on the relationship between sections 41 and 42 of the Expropriations Act in light of its disposition of the first issue. It found this issue should await to be decided in a situation in which it is directly engaged on the facts.

(3) The court saw no reason to extend the principle of full compensation for the costs of collateral civil litigation that expropriated owners may bring to challenge the legality of the expropriation. Although this was a novel issue, the court found the lack of litigation around the meaning of s. 41 of the Expropriations Act over the years suggested no burning public interest to have the legislation clarified. Also, the court did not find the appellant's position to be particularly reasonable. It pursued its own interest with knowledge of the risks, but the court saw no reason why costs should not follow the event as in the normal course.

However, on the appellant's second costs submission, the court agreed that the application judge erred in awarding the School Board costs in the amount of the partial indemnity costs sought by the appellant, as opposed to the amount of substantial indemnity costs sought by the School Board. This effectively awarded the School Board twice the costs it was seeking on the application. The court reduced the School Board's award of costs for the application and fixed the costs of the appeal.

Ross-Clair v. Canada (Attorney General), 2016 ONCA 205

[Gillese, Epstein and Roberts JJ.A.]

Counsel:

Jacqueline Dais-Visca, for the appellant

Jeffrey A. Armel and Daniel T. Resnick, for the respondent

Facts:

The respondent, Ross-Clair, entered into a contract (the "Contract") with Public Works and Government Services Canada ("PWC"). Under the Contract, Ross-Clair agreed to build management offices at the Millhaven Institution (the "Project").

The Contract contained a detailed procedure under which Ross-Clair could claim additional compensation for changes in soil conditions, PWC's neglect or delay (the "Extras"). These provisions can be considered as a "Code" that governed the rights and obligations relating to a claim for Extras. General Condition ("GC") 35.4 was central to this Code and enabled Ross-Clair to submit a claim, in writing, for Extras to the Project Engineer. The claim had to have sufficient information to allow the Engineer to determine whether it was justified. The decision was final and binding, subject only to the dispute resolution conditions found in the Contract (the "DRC"). Under the DRC, Ross-Clair had 15 working days to provide the Engineer with written notice of its dispute. The delivery of this notice would then begin a process that allowed the parties to proceed to binding arbitration.

Ross-Clair advanced a claim for $2,204,676 in Extras (the "Claim"). PWC responded that Ross-Clair had not provided a description of the facts and circumstances giving rise to the Claim sufficient to enable the Engineer to determine whether it was justified. In response, Ross-Clair brought an application under Rule 14.05(3)(d) of the Rules of Civil Procedure for an order requiring PWC to direct the Engineer to consider the Claim and issue a written decision. Once a decision was made, the parties could move on to binding arbitration if necessary.

PWC appealed the application judge's decision that Ross-Clair's claim for $1,437,976 of the $2,204,676 requested met the contractual requirements relevant to advancing a claim for Extras and directed the Engineer to make a decision as to whether the $1,437,976 Claim was justified.

Issues:

(1) What is the standard of review?
(2) Did the $1,437,976 portion of the Claim meet the requirements of GC 35.4?

Holding: Appeal allowed.

Reasoning:

(1) The decision is reviewable on a standard of correctness. PWC admitted that the Contract was unlike a typical standard form contract in that the parties had to agree on an array of clauses. However, these individual clauses were standard in form and were used in all such contracts with the federal government. GC 35.4 had been raised in prior case law and its interpretation would have precedential value. These factors supported the standard of correctness. As well, PWC argued that the application judge committed an extricable error of law by interpreting GC 35.4 without regard to other relevant provisions in the Contract.

The Court disagreed with Ross-Clair's argument that because the Contract allowed for some degree of negotiation, the deferential standard of review confirmed by the Supreme Court in Sattva Capital Corp. v. Creston Moly Corp applies. Although it may be appropriate to regard the Contract as a standard form agreement, the interpretation of which is subject to review on a correctness standard, there was very little evidence of the circumstances surrounding the formation of the contract and what aspects may have been negotiated.

The Court agreed with PWC that when interpreting the Contract, the application judge erred by failing to construe the Contract as a whole. The Supreme Court found in Tercon Contractors Ltd. v. British Columbia (Transportation and Highways) and again in Sattva, that a fundamental principle of contractual interpretation is that the contract must be construed as a whole. In order to properly interpret GC 35.4, the other provisions of the Contract, and specifically those in the Code relating to the claiming of Extras had to be considered.

The application judge recognized his interpretive task as having to determine whether GC 35.4 required "notice of the claim or proof of it". He stated that, unlike the agreement in Technicore Underground Inc. v. Toronto (City), 2012 ONCA 597, the Contract did not contain the phrase "detailed claim" or list specific requirements for the contents of a claim for Extras. On this basis, he concluded that more information than what was contained in Ross-Clair's letters was not required under GC 35.4.

To fulfill their role in the context of the Code, the Engineer requires highly specific information. It was apparent that the application judge in interpreting the information required by GC 35.4 did not take into account the context of the rest of the Contract and, in particular, the Code. This constitutes an extricable error of law.

(2) No. The application judge erred in determining that the $1,437,976 portion of the Claim met the requirements of GC 35.4. The requirement that a contractor submit a claim in writing sufficient to enable the Engineer to determine whether the claim is justified cannot be interpreted in a manner other than that it must be supported by detailed information. The Engineer could not make a decision as to the validity of a claim in the absence of such detailed information. More information was required even with the application judge's finding that the Engineer was intimately familiar with the Project. The Additional Costs Summary included with one of Ross-Clair's letters provided very little information of the amounts attributed to various sub-contractors and no breakdown identifying things like the costs of labour, plant, and material or the amount of the percentage mark-up.

The letters relating to Ross-Clair's Claim were inconsistent and confusing in terms of the location where the extra work was said to be required. The fact that the Engineer and PWC repeatedly asked Ross-Clair to provide more information further supported the Court's conclusion that the $1,437,976 Claim did not meet the requirements of GC 35.4.

Stetler v. Stetler, 2016 ONCA 218

[Strathy C.J.O., Lauwers and Benotto JJ.A]

Counsel:

James A. Brown, for the appellant

Paul D. Amey, for the respondent

Facts:

The appellant loaned her son nearly $40,000. The loan was secured by a mortgage on the son's home. Years later, the son's former spouse, the respondent, sought to sell the home to satisfy an equalization payment owing from the divorce.

She sought a declaration that the mortgage in favour of the appellant was not binding on her and was not an encumbrance on the property. The application judge held that the mortgage was not an encumbrance or charge on the property and that any claim by the appellant on the mortgage was statute-barred. The appellant appeals this decision.

Issues: Did the application judge err in his decision?

Holding: Appeal Dismissed

Reasoning:

No. The appellant sought to rely on fresh evidence to establish acknowledgment of the debt within the limitation period. The fresh evidence consisted of mortgage statements signed by the appellant and further receipts.

The court held that the fresh evidence did not meet the test for admissibility outlined in R. v. Palmer. Firstly, the evidence could have been adduced at trial and secondly, the documents did not satisfy the criteria in s. 23(1) of the Real Property Limitations Act.

The appellant also argued that the application judge erred in not applying the doctrine of promissory estoppel. The appellant submits that he agreed to postpone his son's obligation to pay the debt if his son helped him on his farm. The application judge rejected this submission because the evidence did not establish that there was a promise intended to affect the relationship and a corresponding reliance on the promise. The court agreed with the application judge's reasoning.

Howie, Sacks & Henry LLP v. Chen, 2016 ONCA 213

[LaForme, Pardu and Roberts JJ.A.]

Counsel:

Gary M. Caplan and Justin W. Anisman, for the appellant

David J. Levy, for the respondent, Howie, Sacks and Henry LLP.

Alfred M. Kwinter and Veronica S. Marson, for the respondent, Singer Kwinter

Facts: Mr. Chen was involved in a motor vehicle accident in 2001. After first retaining at least two other law firms, in 2005 Mr. Chen retained the respondent, Howie, Sacks to handle both the accident benefits and tort claims. Howie, Sacks were counsel in 2007 when a settlement was achieved in the benefits claim. In late 2007 Mr. Chen switched counsel, retaining another law firm to represent him in the tort claim, and next retained the respondent, Singer Kwinter in 2010. Singer Kwinter were counsel in 2011, when Mr. Chen's tort claim was settled. Following the settlement of his tort claim, Mr. Chen began various proceedings against some of his previous lawyers including the respondents regarding how his accident claims were handled. To date, none of these proceedings have resulted in any adverse findings against his former lawyers. In 2015, an application brought by the respondent law firms to have Mr. Chen declared a vexatious litigant was heard. Mr. Chen did not file any responding material and was not present or represented by counsel on this occasion. Rather, he had an acquaintance attend on the application to deliver an envelope requesting an adjournment due to illness. The application judge declined Mr. Chen's request for an adjournment, the application was granted, and Mr. Chen was declared a vexatious litigant. He appeals that order.

Issues:

(1) Was Mr. Chen treated unfairly by the court when his adjournment was denied and the application proceeded in his absence?

(2) Did the application judge fail to consider certain factors in applying the test of what constitutes a vexatious litigant under s. 140 of the Courts of Justice Act?

Holding: Appeal dismissed.

Reasoning:

(1) No. The application judge properly exercised his discretion in denying the adjournment. He was presented with documents from Mr. Chen's associate that Mr. Chen could not attend the application because he was too ill. This included emails Mr. Chen sent to counsel advising he was sick, and a prescription for medications. After reviewing the material provided by the associate, the application judge denied the adjournment. None of the material submitted stated that Mr. Chen was ill on the actual hearing date or that he was physically unable to attend the hearing. Mr. Chen is no stranger to court process and procedure and the necessity of placing before the court a proper record for the relief being sought. Further, at the time of the application there were outstanding cost orders totaling $17,769.50 which Mr. Chen had not paid. Moreover, a period of adjournment would have allowed Mr. Chen to continue his other upcoming proceedings and driven up the costs of the litigation against the respondents even further, with little to no hope of them ever being able to recover costs against Mr. Chen.

(2) No. The application judge applied the correct law under section 140 of the Courts of Justice Act in deciding whether to declare Mr. Chen a vexatious litigant. He was aware of the purpose of this legislative provision as well as its limitations and the test to be applied when deciding its application. He was satisfied that Mr. Chen had become a "vexatious litigant" particularly with regard to his pursuit of both applicant law firms including the members, associates and employees in those law firms. He was particularly persuaded by his failure to pay the legal costs awarded against him, which showed a particular lack of respect or regard for the Court and the administration of justice.

Actuate Canada Corporation v. Symcor Services Inc., 2016 ONCA 217

[Gillese, van Rensburg and Miller JJ.A.]

Counsel:

Matthew P. Gottlieb, Daniel A. Schwartz and Laura M. Wagner, for the appellants

Daniel S. Murdoch, Patrick G. Duffy and Sean E. Gibson, for the respondent

Facts:

Xenos' interest in the litigation – its copyright in software referred to as "d2e Software" ("Software") – was transferred to the appellant Actuate Corporation (together "Xenos"). Xenos and Actuate sued licensee Symcor for breach of contract and copyright infringement of the Software. The software was licensed to Symcor in 2001 pursuant to a Licence, Services and Support Agreement (the "LSSA"). Xenos in 2012 asserted that Symcor violated the LSSA in three ways. Symcor admitted to two of Xenos' assertions, but claimed that the LSSA did not restrict these activities. Symcor also raised estoppel and limitation period defences and argued that Xenos consented to Symcor's activities.

Xenos moved for summary judgment on the liability issues and sought an order directing a reference or trial on damages. The motion judge granted this request in part. Specifically, he rejected Xenos's argument that Symcor had breached the LSSA and concluded that the parties' agreement did not restrict Symcor's use to one server per licence. He also concluded, however, that Symcor had breached the licence agreement by using the Software on operating systems other than AIX and with database systems other than CMOD. These were breaches of contract and constituted copyright infringement. Moreover, the motion judge rejected Symcor's defence of estoppel and directed that the limitation period defence proceed as a part of the trial on damages.

Xenos appealed on the basis that the motion judge erred in concluding that the LSSA permitted Symcor to use the Software on more than one server per licence, sought leave to appeal the costs order and argued that the payment of its costs from the summary judgment motion should not await the disposition of the damages trial. Symcor cross-appealed, contending that the motion judge erred in concluding that the LSSA restricted its use of the Software to AIX operating systems and that the motion judge erred in dismissing its estoppel defence. Symcor did not appeal the summary judgment with respect to its use of the Software with database systems other than CMOD.

Issues:

1) Did the motion judge err in interpreting the LSSA as not restricting Symcor's use of the Software to one server per licence?

2) Did the motion judge err in interpreting the LSSA as restricting Symcor's use of the Software to the AIX operating system?

3) Did the motion judge err in rejecting Symcor's estoppel defence and not referring this issue to trial with the limitation period and damages issues?

4) Did the motion judge err in declining to award Xenos its costs of the completed liability phase of the action and in deferring the award of costs of the motion until after the damages trial?

5) Did the motion judge err in fixing costs in favour of Xenos without regard to the divided success on the motion?

Holding: Appeal dismissed; Cross-Appeal Allowed in Part.

Reasoning:

1) No. The motion judge's decision interpreting the contract was entitled to deference. Xenos sought to characterize the motion judge's interpretation as containing extricable errors in principle and palpable and overriding errors of fact, while Symcor contended that the motion judge's interpretation should be subject to a standard of review of palpable and overriding error. The Court found that there was no error in principle and any error of fact did not materially inform the motion judge's decision regarding the scope of and restrictions to Symcor's licences.

2) No. The motion judge considered the broad terms of the LSSA, which contained no restriction on locations from which, or clients for whom, Symcor could use the Software. He noted that the Product Schedules did not speak to the servers, save for a reference in Product Schedule No. 2. He also found Xenos's argument that the Product Schedules refer to one production licence and two non-production licences was not supported by the evidence. Xenos' argument that the motion judge's interpretation contained reviewable errors and palpable and overriding errors of fact was unpersuasive.

3) Yes. The motion judge declined to dismiss Xenos' motion for summary judgment on the basis of the estoppel defence and ordered the limitation defence to proceed as part of the damages trial. Symcor asserted that (1) the motion judge made a palpable and overriding error in stating that there was no evidence that anyone at Xenos with knowledge, responsibility or authority over licensing matters knew of the breaches before 2011 and (2) that it was illogical for the motion judge to dismiss the estoppel defence while allowing the limitation defence. The Court accepted these arguments, finding that there was evidence in the record of communications within Xenos that included the responsible account managers in 2005 and 2007, where it was apparent that Symcor was using the Software on Windows. The motion judge's rejection of the estoppel defence was heavily reliant on the finding that there was no evidence as discussed above, and thus his decision concerning the estoppel defence was a palpable and overriding error.

4) No. There was no error and the motion judge's approach here was sensible. The motion judge exercised his discretion in making his order but left the determination of whether Xenos should be awarded its costs to the trial judge. This order permitted the necessary flexibility in the event that Xenos was eventually awarded lesser damages than provided for in Symcor's outstanding offer.

5) Yes. The Court did not interfere with the motion judge's assessment that Xenos was substantially successful on the motion and was thus entitled to its costs, subject to the outcome of the trial. However, while the Court did not give effect to either side's argument with respect to the motion judge's disposition of costs of the summary judgment motion, it set aside the costs order in light of Symcor's partial success on its cross-appeal.

ONTARIO REVIEW BOARD DECISIONS

Shipman (Re) 2016 ONCA 209

[Feldman, Gillese and Huscroft JJ.A.]

Counsel:
Meaghan McMahon, for James Shipman
Rochelle Direnfeld, for the Attorney General
Michelle O'Bonsawin, for the Royal Ottawa Health Care Group

Keywords: Review Board, Status Report, Absolute Discharge, Public Safety, Supervised Community Care

CRIMINAL LAW DECISIONS

R. c. A.L., 2016 ONCA 201

[La juge en chef adjointe Hoy et les juges Pardu et Roberts]

Counsel :
Yves Jubinville, pour l'appelant
Philippe Cowle, pour l'intimée

Keywords: Criminal Law, Sexual Assault, Witness Testimony, Credibility, Child Testimony

R v. Simpson, 2016 ONCA 212

[Feldman, Gillese and Huscroft JJ.A.]

Counsel:
Benjamin Goldman, for the appellant
Shawn Porter, for the respondent

Keywords: Criminal Law, Functus Officio, Fresh Evidence

R. v. McLellan, 2016 ONCA 215

[Doherty, Simmons and van Rensburg JJ.A.]

Counsel:
Paul Calarco, for the appellant
Jessica Smithjoy, for the respondent

Keywords: Criminal Law, Sentencing, Demonstrably Unfit

R. v. Vernon, 2016 ONCA 211

[Feldman, Gillese and Huscroft JJ.A.]

Counsel:
Michael Fawcett, for the appellant
Adam Little, for the respondent

Keywords: Criminal Law, Right to Counsel, Charter, Section 10(b)

R. v. Abbasi, 2016 ONCA 219

[Doherty, Simmons and van Rensburg JJ.A.]

Counsel:
Peter Copeland, for the appellant
Jessica Smith Joy, for the respondent

Keywords: Criminal Law, Firearms, Sentencing

R. v. J.L., 2016 ONCA 221

[Doherty, Simmons and van Rensburg JJ.A.]

Counsel:
John Hale, for the appellant
Michael Fawcett, for the respondent

Keywords: Criminal Law, Sexual Assault, Fair Trial, Ineffective Counsel

IMMIGRATION DECISIONS

Canada (Attorney General) v. Mgbolu, 2016 ONCA 216

[Doherty, Simmons and van Rensburg JJ.A.]

Counsel:
Laurence Cohen, for the appellant
Nancy Dennison, for the respondent

Keywords: Immigration Law, Judicial Review, Extradition, Extradition Act, Section 57, Disclosure, Cotroni Assessment

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
John Polyzogopoulos
Similar Articles
Relevancy Powered by MondaqAI
 
In association with
Related Topics
 
Similar Articles
Relevancy Powered by MondaqAI
Related Articles
 
Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration (you must scroll down to set your data preferences)

Mondaq Ltd requires you to register and provide information that personally identifies you, including your content preferences, for three primary purposes (full details of Mondaq’s use of your personal data can be found in our Privacy and Cookies Notice):

  • To allow you to personalize the Mondaq websites you are visiting to show content ("Content") relevant to your interests.
  • To enable features such as password reminder, news alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our content providers ("Contributors") who contribute Content for free for your use.

Mondaq hopes that our registered users will support us in maintaining our free to view business model by consenting to our use of your personal data as described below.

Mondaq has a "free to view" business model. Our services are paid for by Contributors in exchange for Mondaq providing them with access to information about who accesses their content. Once personal data is transferred to our Contributors they become a data controller of this personal data. They use it to measure the response that their articles are receiving, as a form of market research. They may also use it to provide Mondaq users with information about their products and services.

Details of each Contributor to which your personal data will be transferred is clearly stated within the Content that you access. For full details of how this Contributor will use your personal data, you should review the Contributor’s own Privacy Notice.

Please indicate your preference below:

Yes, I am happy to support Mondaq in maintaining its free to view business model by agreeing to allow Mondaq to share my personal data with Contributors whose Content I access
No, I do not want Mondaq to share my personal data with Contributors

Also please let us know whether you are happy to receive communications promoting products and services offered by Mondaq:

Yes, I am happy to received promotional communications from Mondaq
No, please do not send me promotional communications from Mondaq
Terms & Conditions

Mondaq.com (the Website) is owned and managed by Mondaq Ltd (Mondaq). Mondaq grants you a non-exclusive, revocable licence to access the Website and associated services, such as the Mondaq News Alerts (Services), subject to and in consideration of your compliance with the following terms and conditions of use (Terms). Your use of the Website and/or Services constitutes your agreement to the Terms. Mondaq may terminate your use of the Website and Services if you are in breach of these Terms or if Mondaq decides to terminate the licence granted hereunder for any reason whatsoever.

Use of www.mondaq.com

To Use Mondaq.com you must be: eighteen (18) years old or over; legally capable of entering into binding contracts; and not in any way prohibited by the applicable law to enter into these Terms in the jurisdiction which you are currently located.

You may use the Website as an unregistered user, however, you are required to register as a user if you wish to read the full text of the Content or to receive the Services.

You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these Terms or with the prior written consent of Mondaq. You may not use electronic or other means to extract details or information from the Content. Nor shall you extract information about users or Contributors in order to offer them any services or products.

In your use of the Website and/or Services you shall: comply with all applicable laws, regulations, directives and legislations which apply to your Use of the Website and/or Services in whatever country you are physically located including without limitation any and all consumer law, export control laws and regulations; provide to us true, correct and accurate information and promptly inform us in the event that any information that you have provided to us changes or becomes inaccurate; notify Mondaq immediately of any circumstances where you have reason to believe that any Intellectual Property Rights or any other rights of any third party may have been infringed; co-operate with reasonable security or other checks or requests for information made by Mondaq from time to time; and at all times be fully liable for the breach of any of these Terms by a third party using your login details to access the Website and/or Services

however, you shall not: do anything likely to impair, interfere with or damage or cause harm or distress to any persons, or the network; do anything that will infringe any Intellectual Property Rights or other rights of Mondaq or any third party; or use the Website, Services and/or Content otherwise than in accordance with these Terms; use any trade marks or service marks of Mondaq or the Contributors, or do anything which may be seen to take unfair advantage of the reputation and goodwill of Mondaq or the Contributors, or the Website, Services and/or Content.

Mondaq reserves the right, in its sole discretion, to take any action that it deems necessary and appropriate in the event it considers that there is a breach or threatened breach of the Terms.

Mondaq’s Rights and Obligations

Unless otherwise expressly set out to the contrary, nothing in these Terms shall serve to transfer from Mondaq to you, any Intellectual Property Rights owned by and/or licensed to Mondaq and all rights, title and interest in and to such Intellectual Property Rights will remain exclusively with Mondaq and/or its licensors.

Mondaq shall use its reasonable endeavours to make the Website and Services available to you at all times, but we cannot guarantee an uninterrupted and fault free service.

Mondaq reserves the right to make changes to the services and/or the Website or part thereof, from time to time, and we may add, remove, modify and/or vary any elements of features and functionalities of the Website or the services.

Mondaq also reserves the right from time to time to monitor your Use of the Website and/or services.

Disclaimer

The Content is general information only. It is not intended to constitute legal advice or seek to be the complete and comprehensive statement of the law, nor is it intended to address your specific requirements or provide advice on which reliance should be placed. Mondaq and/or its Contributors and other suppliers make no representations about the suitability of the information contained in the Content for any purpose. All Content provided "as is" without warranty of any kind. Mondaq and/or its Contributors and other suppliers hereby exclude and disclaim all representations, warranties or guarantees with regard to the Content, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. To the maximum extent permitted by law, Mondaq expressly excludes all representations, warranties, obligations, and liabilities arising out of or in connection with all Content. In no event shall Mondaq and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use of the Content or performance of Mondaq’s Services.

General

Mondaq may alter or amend these Terms by amending them on the Website. By continuing to Use the Services and/or the Website after such amendment, you will be deemed to have accepted any amendment to these Terms.

These Terms shall be governed by and construed in accordance with the laws of England and Wales and you irrevocably submit to the exclusive jurisdiction of the courts of England and Wales to settle any dispute which may arise out of or in connection with these Terms. If you live outside the United Kingdom, English law shall apply only to the extent that English law shall not deprive you of any legal protection accorded in accordance with the law of the place where you are habitually resident ("Local Law"). In the event English law deprives you of any legal protection which is accorded to you under Local Law, then these terms shall be governed by Local Law and any dispute or claim arising out of or in connection with these Terms shall be subject to the non-exclusive jurisdiction of the courts where you are habitually resident.

You may print and keep a copy of these Terms, which form the entire agreement between you and Mondaq and supersede any other communications or advertising in respect of the Service and/or the Website.

No delay in exercising or non-exercise by you and/or Mondaq of any of its rights under or in connection with these Terms shall operate as a waiver or release of each of your or Mondaq’s right. Rather, any such waiver or release must be specifically granted in writing signed by the party granting it.

If any part of these Terms is held unenforceable, that part shall be enforced to the maximum extent permissible so as to give effect to the intent of the parties, and the Terms shall continue in full force and effect.

Mondaq shall not incur any liability to you on account of any loss or damage resulting from any delay or failure to perform all or any part of these Terms if such delay or failure is caused, in whole or in part, by events, occurrences, or causes beyond the control of Mondaq. Such events, occurrences or causes will include, without limitation, acts of God, strikes, lockouts, server and network failure, riots, acts of war, earthquakes, fire and explosions.

By clicking Register you state you have read and agree to our Terms and Conditions