Australia: Projects Disputes Cases In Australia: Recent Cases

During the second half of 2016, a number of high-profile cases across Australia have offered significant insights to stakeholders in the construction and mining industries. Below, we review several of the key ones.

New South Wales

Case: Probuild Constructions (Aust) Pty Ltd v Shade Systems Pty Ltd [2016] NSWSC 77

The scope for challenging an adjudicator's decision in New South Wales may have expanded.

Earlier this year, a single judge of the New South Wales ("NSW") Supreme Court held that the Court has jurisdiction to review an adjudication for any error of law on the face of the record. This represented a significant expansion of the grounds on which a court can review an adjudication, which was previously limited to the confined notion of jurisdictional error (including noncompliance with the essential elements of the legislation, such as invalidity of the payment claim).

The decision concerned a contract between Shade Systems ("Shade") and Probuild Constructions ("Probuild)" under which Shade agreed to supply and install external louvers to the facade of an apartment complex. Shade issued a payment claim for $324,334 under the Building and Construction Industry Security of Payment Act 1999 (NSW), but Probuild rejected the claim in its payment schedule on the basis that it was entitled to liquidated damages of $1,089,900 from Shade. An adjudicator awarded $277,755 to Shade and rejected Probuild's liquidated damages claim.

Probuild challenged the decision in the NSW Supreme Court, and was successful on its alternative argument that although there was no jurisdictional error, the decision should be quashed by the Court because the rejection of the liquidated damages claim involved an error of law on the face of the record. The Court held that the adjudicator had wrongly assumed that the onus was on Probuild to demonstrate that Shade was at fault for the failure to achieve practical completion on time.

The decision is significant because it potentially opens the door to greater judicial scrutiny of adjudication decisions, which may result in less certainty and more disputes for the industry.

However, it is important to note that the position is not yet settled—the decision is controversial given previous case law, and Shade has brought an appeal which is due to be heard in December 2016. In a decision staying the original costs order in favour of Probuild pending the outcome of the appeal, the Court recognised the "public importance" of the issue and held that Shade has reasonable prospects of reversing the decision in its appeal, so a decision by the NSW Court of Appeal will bring welcome clarity to the industry.

High Court of Australia

Case: Paciocco v ANZ [2016] HCA 28

High Court clarification on the penalties doctrine, which has important implications for the enforcement of liquidated damages clauses.

By way of reminder, this dispute concerned the question of whether late payment fees charged by a bank (ANZ), constituted a penalty, but has been cause for wider interest given the impact on the penalties doctrine across a range of industries, including in the context of liquidated damages clauses in construction contracts and disputes.

The Federal Court had originally held that the late payment fees were impermissible as penalties, on the basis that they were extravagant and unconscionable when compared to the actual loss suffered by the bank. On appeal, the Full Federal Court overturned that decision, and the High Court has now agreed with the Full Federal Court.

The High Court decision confirms that a payment on default or breach of contract will only be a penalty if it is "out of all proportion to the interest of the party which the provision seeks to protect". This is a high bar. More importantly, the High Court has clarified that this must take into account the totality of the party's interests and is not confined to losses or expenses directly caused by the breach.

Within the construction industry, the decision will also make it harder to argue that a liquidated damages clause for delay on a project is a penalty. This is because, particularly on large projects, delay can have a large number of indirect impacts which principals can point to as part of the legitimate interests to be protected by a liquidated damages clause under the test confirmed by the High Court. This can be the case whether the assessment of that legitimate interest is one of the damages actually suffered upon a particular delay, or a prospective estimate of the damages made prior to commencement of the project. However, it is perhaps even easier to do so on a prospective basis when there may be additional factors that represent realistic commercial risks even if many of them may not actually come to pass in the event of a particular delay.

Victoria

Case: SSC Plenty Road Pty Ltd v Construction Engineering (Aust) Pty Ltd [2016] VSCA 119

Mediation is not a "method of resolving disputes" for the purpose of Security of Payment legislation.

The Victorian Court of Appeal was recently asked to consider the validity of a determination by an adjudicator appointed under the Building and Construction Industry Security of Payment Act 2002 (Vic) ("Victorian Act").

In calculating a progress payment due under the construction contract ("the contract"), the adjudicator took into account "variations" to the contract pursuant to s10A of the Victorian Act. That section permits variations to be taken into account in certain circumstances, including: (i) where the contract sum does not exceed $5.0 million; or (ii) where the contract sum exceeds $5.0 million, but the contract "does not provide a method of resolving disputes under the contract". The dispute resolution process under the contract required the parties' representatives to meet to try to resolve the dispute, and, if unsuccessful, to attend mediation. If the mediation was unsuccessful, the parties were entitled to pursue their rights at law. The adjudicator considered that the contract did not provide for a dispute resolution method and thus took into account the variations in determining the amount of the progress payment.

The principal challenged the adjudicator's determination in the Victorian Supreme Court, arguing that the contractual requirement of mediation constituted a "method of resolving disputes". such that the adjudicator was not entitled to consider variations pursuant to s10A of the Victorian Act.

At first instance and on appeal, the adjudicator's decision was upheld. The Court of Appeal held that the purpose of s10A is to ensure that parties have available a means of finally determining an entitlement to a progress payment, rather than a mere forum to address the controversies between them. Accordingly, mediation is not a "method of resolving disputes" for the purposes of s 10A(3)(d)(ii) of the Victorian Act because it does not ensure a final resolution.

A second issue before the Court was whether the adjudicator was bound to adopt the value of work determined by the superintendent (under powers conferred by the contract). The Court held that the role of the adjudicator is entirely statutory, not contractual, so the adjudicator's valuation was not constrained by the terms of the contract. Requiring the adjudicator to simply adopt the price of the superintendent would be inconsistent with the adjudicator's statutory obligation to independently assess the value of the progress payment.

The case helpfully demonstrates that if contractors wish to avoid adjudicating disputed variations under the Victorian Act, they must ensure the contract includes a dispute resolution process capable of ensuring a final determination. While the process may include mediation (as many such provisions commonly do), there must be further steps that ensure a resolution (other than legal proceedings) in the event mediation is unsuccessful (for example, a binding third party determination).

Western Australia

Case: Ralmana Pty Ltd v BGC Contracting Pty Ltd [2016] WASC 131

When claiming an EOT or delay costs in legal proceedings, a party must plead and prove the satisfaction of any conditions precedent, including notice provisions.

The Western Australian Supreme Court considered an application to strike out claims in respect of an Extension of Time ("EOT") and associated delay costs, on the ground that the claimant had not pleaded satisfaction of a notice requirement that applied to EOTs under the relevant contract.

BGC Contracting ("BGC") subcontracted Ralmana Pty Ltd ("Ralmana") to carry out excavation and filling of earthworks for rail embankments, roads and associated works for the purpose of building the roads and rail for the Roy Hill Project. The subcontract required that in order to claim an EOT, Ralmana was required to request an EOT from BGC's designated representative under the subcontract.

Ralmana commenced proceedings against BGC claiming $33 million for delay costs (including due to access and site problems). Ralmana's claim did not positively plead satisfaction of the requirement to first request an EOT from BGC's designated representative. BGC sought to strike out the claim on that basis. In response, Ralmana argued that any non-satisfaction with the requirement was a matter to be raised and proved by BGC, and that in the absence of it doing so, the Court should assume satisfaction of the requirement.

The Court rejected Ralmana's argument and struck out the EOT claims accordingly. It held that satisfaction of a condition precedent for the claim for a liquidated sum (including an EOT), such as a notice provision, is a matter which must be positively pleaded and proved by a claimant. To do otherwise would in effect ignore the express provisions of the contract.

When claiming an EOT or delay costs in legal proceedings, a party will need to establish the satisfaction of any contractual conditions precedent to making the claim. This makes it important that contractors comply with any notice requirements or other preconditions for any time or money claims, and maintain records of doing so in order to support any subsequent proceedings should a dispute arise.

Queensland

Case: Armour Energy Limited v AEGP Australia Pty Ltd [2016] QSC 153

Interpretation of a condition precedent in an exploration farm-out agreement highlights the importance of clear drafting

The Queensland Supreme Court considered the proper interpretation of a farm-out agreement ("Agreement") in which Armour Energy Limited ("Armour") agreed to sell a 75 per cent interest in petroleum exploration permits to AEGP Australia Pty Ltd ("AEGP"). Armour sought specific performance of the Agreement. In determining the application, the key question was whether a condition precedent had been satisfied. It required execution of a Deed of Assignment and Assumption ("DOAA") by Armour, AEGP, the Northern Land Council ("Council") and the Native Title Parties, for the purpose of assigning the rights and obligations owed to the relevant Native Title Parties under the exploration permits.

Instead of the DOAA, the Council executed a Deed of Covenant ("Deed") in respect of each existing Native Title Agreement. Armour argued that execution of the Deed satisfied the condition precedent because it had the effect of obtaining the consent of the Native Title Parties to a novation and assignment of the exploration permits to AEGP, by the Council acting on behalf of the Native Title Parties (as their legal representative). Conversely, AEGP argued that, for the condition precedent to be satisfied, each Native Title Party had to execute the DOAA in the form annexed to the Agreement.

There was clearly a degree of ambiguity in the drafting of the relevant clause. Further, the draft DOAA annexed to the Agreement failed to identify the names of the Native Title Parties. Nonetheless, the Court was able to resolve this by finding that the terms of each Native Title Agreement were incorporated by reference into the Agreement. The Court held that, viewed objectively, in the context of the Agreement as a whole, the clause did not require strict execution of the DOAA by each Native Title Party. Instead, the Deed simply had to be substantially in the form of the draft DOAA (which it was). As each Native Title Agreement had been novated, the execution of each Deed by the Council was sufficient to bind the assignee (AEGP) to the rights and obligations under the exploration permits. As the condition precedent was satisfied, the Court ordered that the Agreement be specifically performed.

As well as providing a timely reminder of the importance of clear and unambiguous drafting when setting conditions precedent in mining contracts, this case demonstrates that the native title consequences when assigning rights to rural land (in particular mining permits) are not mere formalities. The specific rights and obligations to the native title stakeholders should always be clarified when buying and selling such interests. This will help to ensure that the relevant conditions precedent can be easily satisfied so that there are no unintended consequences and no difficulties in enforcing the agreement in the future.

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

To print this article, all you need is to be registered on Mondaq.com.

Click to Login as an existing user or Register so you can print this article.

Authors
Steven W. Fleming
 
Some comments from our readers…
“The articles are extremely timely and highly applicable”
“I often find critical information not available elsewhere”
“As in-house counsel, Mondaq’s service is of great value”

Related Video
Up-coming Events Search
Tools
Print
Font Size:
Translation
Channels
Mondaq on Twitter
 
Register for Access and our Free Biweekly Alert for
This service is completely free. Access 250,000 archived articles from 100+ countries and get a personalised email twice a week covering developments (and yes, our lawyers like to think you’ve read our Disclaimer).
 
Email Address
Company Name
Password
Confirm Password
Position
Mondaq Topics -- Select your Interests
 Accounting
 Anti-trust
 Commercial
 Compliance
 Consumer
 Criminal
 Employment
 Energy
 Environment
 Family
 Finance
 Government
 Healthcare
 Immigration
 Insolvency
 Insurance
 International
 IP
 Law Performance
 Law Practice
 Litigation
 Media & IT
 Privacy
 Real Estate
 Strategy
 Tax
 Technology
 Transport
 Wealth Mgt
Regions
Africa
Asia
Asia Pacific
Australasia
Canada
Caribbean
Europe
European Union
Latin America
Middle East
U.K.
United States
Worldwide Updates
Registration
Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:
  • To allow you to personalize the Mondaq websites you are visiting.
  • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
  • To produce demographic feedback for our information providers who provide information free for your use.
  • Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.
    If you do not want us to provide your name and email address you may opt out by clicking here
    If you do not wish to receive any future announcements of products and services offered by Mondaq you may opt out by clicking here

    Terms & Conditions and Privacy Statement

    Mondaq.com (the Website) is owned and managed by Mondaq Ltd and as a user you are granted a non-exclusive, revocable license to access the Website under its terms and conditions of use. Your use of the Website constitutes your agreement to the following terms and conditions of use. Mondaq Ltd may terminate your use of the Website if you are in breach of these terms and conditions or if Mondaq Ltd decides to terminate your license of use for whatever reason.

    Use of www.mondaq.com

    You may use the Website but are required to register as a user if you wish to read the full text of the content and articles available (the Content). You may not modify, publish, transmit, transfer or sell, reproduce, create derivative works from, distribute, perform, link, display, or in any way exploit any of the Content, in whole or in part, except as expressly permitted in these terms & conditions or with the prior written consent of Mondaq Ltd. You may not use electronic or other means to extract details or information about Mondaq.com’s content, users or contributors in order to offer them any services or products which compete directly or indirectly with Mondaq Ltd’s services and products.

    Disclaimer

    Mondaq Ltd and/or its respective suppliers make no representations about the suitability of the information contained in the documents and related graphics published on this server for any purpose. All such documents and related graphics are provided "as is" without warranty of any kind. Mondaq Ltd and/or its respective suppliers hereby disclaim all warranties and conditions with regard to this information, including all implied warranties and conditions of merchantability, fitness for a particular purpose, title and non-infringement. In no event shall Mondaq Ltd and/or its respective suppliers be liable for any special, indirect or consequential damages or any damages whatsoever resulting from loss of use, data or profits, whether in an action of contract, negligence or other tortious action, arising out of or in connection with the use or performance of information available from this server.

    The documents and related graphics published on this server could include technical inaccuracies or typographical errors. Changes are periodically added to the information herein. Mondaq Ltd and/or its respective suppliers may make improvements and/or changes in the product(s) and/or the program(s) described herein at any time.

    Registration

    Mondaq Ltd requires you to register and provide information that personally identifies you, including what sort of information you are interested in, for three primary purposes:

    • To allow you to personalize the Mondaq websites you are visiting.
    • To enable features such as password reminder, newsletter alerts, email a colleague, and linking from Mondaq (and its affiliate sites) to your website.
    • To produce demographic feedback for our information providers who provide information free for your use.

    Mondaq (and its affiliate sites) do not sell or provide your details to third parties other than information providers. The reason we provide our information providers with this information is so that they can measure the response their articles are receiving and provide you with information about their products and services.

    Information Collection and Use

    We require site users to register with Mondaq (and its affiliate sites) to view the free information on the site. We also collect information from our users at several different points on the websites: this is so that we can customise the sites according to individual usage, provide 'session-aware' functionality, and ensure that content is acquired and developed appropriately. This gives us an overall picture of our user profiles, which in turn shows to our Editorial Contributors the type of person they are reaching by posting articles on Mondaq (and its affiliate sites) – meaning more free content for registered users.

    We are only able to provide the material on the Mondaq (and its affiliate sites) site free to site visitors because we can pass on information about the pages that users are viewing and the personal information users provide to us (e.g. email addresses) to reputable contributing firms such as law firms who author those pages. We do not sell or rent information to anyone else other than the authors of those pages, who may change from time to time. Should you wish us not to disclose your details to any of these parties, please tick the box above or tick the box marked "Opt out of Registration Information Disclosure" on the Your Profile page. We and our author organisations may only contact you via email or other means if you allow us to do so. Users can opt out of contact when they register on the site, or send an email to unsubscribe@mondaq.com with “no disclosure” in the subject heading

    Mondaq News Alerts

    In order to receive Mondaq News Alerts, users have to complete a separate registration form. This is a personalised service where users choose regions and topics of interest and we send it only to those users who have requested it. Users can stop receiving these Alerts by going to the Mondaq News Alerts page and deselecting all interest areas. In the same way users can amend their personal preferences to add or remove subject areas.

    Cookies

    A cookie is a small text file written to a user’s hard drive that contains an identifying user number. The cookies do not contain any personal information about users. We use the cookie so users do not have to log in every time they use the service and the cookie will automatically expire if you do not visit the Mondaq website (or its affiliate sites) for 12 months. We also use the cookie to personalise a user's experience of the site (for example to show information specific to a user's region). As the Mondaq sites are fully personalised and cookies are essential to its core technology the site will function unpredictably with browsers that do not support cookies - or where cookies are disabled (in these circumstances we advise you to attempt to locate the information you require elsewhere on the web). However if you are concerned about the presence of a Mondaq cookie on your machine you can also choose to expire the cookie immediately (remove it) by selecting the 'Log Off' menu option as the last thing you do when you use the site.

    Some of our business partners may use cookies on our site (for example, advertisers). However, we have no access to or control over these cookies and we are not aware of any at present that do so.

    Log Files

    We use IP addresses to analyse trends, administer the site, track movement, and gather broad demographic information for aggregate use. IP addresses are not linked to personally identifiable information.

    Links

    This web site contains links to other sites. Please be aware that Mondaq (or its affiliate sites) are not responsible for the privacy practices of such other sites. We encourage our users to be aware when they leave our site and to read the privacy statements of these third party sites. This privacy statement applies solely to information collected by this Web site.

    Surveys & Contests

    From time-to-time our site requests information from users via surveys or contests. Participation in these surveys or contests is completely voluntary and the user therefore has a choice whether or not to disclose any information requested. Information requested may include contact information (such as name and delivery address), and demographic information (such as postcode, age level). Contact information will be used to notify the winners and award prizes. Survey information will be used for purposes of monitoring or improving the functionality of the site.

    Mail-A-Friend

    If a user elects to use our referral service for informing a friend about our site, we ask them for the friend’s name and email address. Mondaq stores this information and may contact the friend to invite them to register with Mondaq, but they will not be contacted more than once. The friend may contact Mondaq to request the removal of this information from our database.

    Emails

    From time to time Mondaq may send you emails promoting Mondaq services including new services. You may opt out of receiving such emails by clicking below.

    *** If you do not wish to receive any future announcements of services offered by Mondaq you may opt out by clicking here .

    Security

    This website takes every reasonable precaution to protect our users’ information. When users submit sensitive information via the website, your information is protected using firewalls and other security technology. If you have any questions about the security at our website, you can send an email to webmaster@mondaq.com.

    Correcting/Updating Personal Information

    If a user’s personally identifiable information changes (such as postcode), or if a user no longer desires our service, we will endeavour to provide a way to correct, update or remove that user’s personal data provided to us. This can usually be done at the “Your Profile” page or by sending an email to EditorialAdvisor@mondaq.com.

    Notification of Changes

    If we decide to change our Terms & Conditions or Privacy Policy, we will post those changes on our site so our users are always aware of what information we collect, how we use it, and under what circumstances, if any, we disclose it. If at any point we decide to use personally identifiable information in a manner different from that stated at the time it was collected, we will notify users by way of an email. Users will have a choice as to whether or not we use their information in this different manner. We will use information in accordance with the privacy policy under which the information was collected.

    How to contact Mondaq

    You can contact us with comments or queries at enquiries@mondaq.com.

    If for some reason you believe Mondaq Ltd. has not adhered to these principles, please notify us by e-mail at problems@mondaq.com and we will use commercially reasonable efforts to determine and correct the problem promptly.

    By clicking Register you state you have read and agree to our Terms and Conditions